Procedeo Core Construction Jobs in Usa

Position Summary

The Construction Program Manager oversees a portfolio of construction projects and ensures they are delivered safely, on schedule, within budget, and in alignment with organizational goals. This role coordinates multiple site managers, contractors, consultants, and internal stakeholders to successfully execute capital construction programs from planning through completion. The Construction Program Manager provides strategic oversight, manages risks, ensures compliance with regulations, and drives consistent project delivery standards across all projects.

Key Responsibilities

• Lead and manage multiple construction projects within a larger capital program.
• Develop and maintain overall program schedules, budgets, and delivery strategies.
• Supervise and support project managers, site managers, and project teams.
• Coordinate with architects, engineers, contractors, subcontractors, and regulatory agencies.
• Oversee procurement processes including RFPs, contractor selection, and contract negotiations.
• Monitor construction progress and ensure adherence to timelines, quality standards, and budgets.
• Identify program risks and implement mitigation strategies.
• Ensure compliance with safety regulations, building codes, and permitting requirements.
• Review project documentation including drawings, schedules, cost reports, and change orders.
• Manage program financials including forecasting, cost tracking, and reporting.
• Provide regular status reports to senior leadership and stakeholders.
• Drive process improvements and standardization across construction projects.

Required Qualifications

• Bachelor’s degree in Construction Management, Civil Engineering, Architecture, or related field.

• Experience managing large-scale commercial, infrastructure, or capital construction projects.

• Strong knowledge of construction methods, building codes, and project delivery processes.

• Proven ability to manage budgets, schedules, and multiple stakeholders.

• Strong leadership, negotiation, and communication skills.

Preferred Qualifications

• Professional certifications such as PMP, CCM (Certified Construction Manager), or LEED accreditation.

• Experience managing multi-site or multi-million-dollar construction programs.

• Familiarity with construction management software (Procore, Primavera P6, Autodesk Construction Cloud, Bluebeam, etc.).

Key Skills

• Construction program management

• Budgeting and cost control

• Contract administration

• Risk and safety management

• Schedule management

• Stakeholder coordination

• Leadership and team development

Typical Work Environment

• Combination of office and active construction site environments.

• Regular site visits required.

• Will require travel between project locations.

USI Core Values

• Wide Awake – Upbeat; Sense of urgency; Work hard, play hard.

• Self-Starter – Wants to take the lead; Goal-driven; Think ahead.

• Pride in Work – Overachiever; Wants to grow; Integrity.

• Problem Solver – Communicate to the right people; Thinks outside of the box; Doesn’t make the same mistakes twice.

• I’ve Got Your Back – Team; All components lead to success; Flexible.

Macro-Z-Technology (MZT) is a leading construction company known for building exceptional projects through an unwavering commitment to its people. With a strong reputation in the Federal and Municipal construction markets, MZT has built everything from roadways and dams to multi-story building construction and complete facility renovations. With an in-house design department, we specialize in design-build projects.

As a Senior Project Manager at MZT, you’ll play a pivotal role in overseeing the successful completion of our largest construction projects. You will be responsible for managing the entire project lifecycle, which includes ensuring adherence to timelines, budget, and quality standards. You’ll interface regularly with the Client, Client stakeholders, and other construction professionals to resolve project challenges. Your strong leadership, organizational skills, and construction expertise will be vital in driving the successful completion of projects that are safe, on-time, within budget, and leave the Client satisfied.

We are looking for Senior Project Managers with experience working on Federal and Civil construction projects (roads/bridges, wastewater/sewer systems, railways, tunnels, dams, airports, etc.). While we appreciate candidates from other construction backgrounds only those with Civil construction experience will be considered.

Company Culture

• MZT covers 100% of the premium for medical, vision, and dental insurance for you and your family because we want you to be well. You won’t find this benefit anywhere else.
• MZT supports professional development. Whatever your growth goals are, we’re here to provide support. We offer an incentive for you to get your PMP or CCM certification within your first six months of joining our team.
• MZT trusts your skills and expertise. We encourage our Construction Project Managers to exercise their judgment, explore innovative approaches, and seize opportunities for growth, while guided by our core values to delivering projects that align with our commitment to excellence.
• Teamwork is at the heart of everything we do. As part of our team, you will be an integral part of a collaborative and supportive environment. We value the power of collective knowledge and believe that together we can achieve remarkable results.
• You’ll work directly with the company owner – your voice will be heard.
• Room for growth? You bet! Over 20% of MZT’s key leaders started in the field.

Key Responsibilities

• Project planning and execution, budgeting and cost control, team leadership and collaboration, and quality assurance and safety compliance on assigned projects.
• Develop project, schedule and monitor project milestones and effectively schedule appropriate employees and contractors (with strong support from the Superintendent) for best quality work in timely fashion.
• Ensure compliance with federal, state, local, industry, contractual, and company regulations, standards, specifications, and best practices.
• Contribute to pre-construction phase including scheduling, constructability review, estimating, bidding, and interfacing with our in-house design department.
• Prepare necessary documentation, such as RFIs, submittals, subcontracts, change orders, etc.
• Serve as primary point of contact for the Superintendent, consultants, contractors, and others as appropriate to each project.
• Effectively motivate and manage in-field managers and subs for timely project completion.
• Lead the buyout process for your assigned project(s). Negotiate with subcontractors.
• Communicate project milestones to stakeholders at regularly scheduled meetings and as needed throughout the project lifecycle.
• Attend all design and construction meetings, such as Post-Award Kickoff (PAK).
• Support the Superintendent in resolving in-field challenges with construction or personnel issues.
• Coordinate building structure as well as related aspects (e.g., mechanical, plumbing, electrical) with subcontractors and related personnel.
• Prepare and present a Monthly Project Review report.
• Certify and sign statement on each invoice that all work to be paid under the invoice has been completed in accordance with contract requirements.
• Perform other duties as assigned.

Qualifications & Experience

• Bachelor’s degree in construction management, civil engineering, building construction, or related field is preferred.
• Minimum 8 years’ experience in construction management overseeing multiple, concurrent projects as a Project Engineer, PM, or equivalent role.
• MUST HAVE proven background in Federal and/or Military construction projects
• Knowledge of the FARS is preferred.
• Knowledge of Federal procedures is preferred.
• EM 385 USACE Certification preferred.
• PMP or CCM certification is preferred
• Experience in both civil/ horizontal and building/ vertical construction
• Demonstrated experience in mid-level construction management on commercial, public works, or government construction projects.
• Communication skills will be subject to assessment in both verbal and written form—business correspondence as well as ad-hoc in-field communication will both be strong demands in this position

Technical Skills

• Proficient in Microsoft Office: Excel, Word, Outlook, Teams, etc.
• Proficient in Primavera P6 (prefer to see certification as well)
• Other construction management platform experience desired (e.g., Procore, RMS, Oracle, eCMS, etc.)

What We Offer

• Salary: $140,000 - $170,000 per year DOE
• Sign On Bonus - $10,000
• Health, dental, and vision insurance premiums 100% paid for you and your dependents
• Life Insurance (100% premium paid by the company for the employee only)
• 401(k) with 100% match up to 4% of salary
• Paid time off
• Opportunity for bonuses based on performance

Schedule

• Full time
• Hours vary, weekend work may be required
• In office or on-site where the project is located
• Must be willing to travel

EEO

We’re dedicated to creating a respectful workplace that values diversity and offers equal employment opportunities for all qualified candidates. We celebrate our diverse team and ensure that every applicant is considered based solely on qualifications, without discrimination. We abide by the requirements of 41 CFR 60-741.5. This regulation prohibits discrimination against qualified individuals on the basis of disability, and requires affirmative action by covered prime contractors and subcontractors to employee and advance in employment qualified individuals with disabilities.

VEVRAA/This contractor shall abide by the requirements of 41 CFR 60-300.5(a). This regulation prohibits discrimination against qualified protected veterans, and requires affirmative action by covered prime contractors and subcontractors to employee and advance in employment qualified protected veterans.

Company Overview

Bashas’ is a family-owned, regional grocer that operates in Arizona, New Mexico and serves four Tribal Nations under five well-known brands including Bashas’, Food City, AJ’s Fine Foods, Eddie’s Country Store, and Bashas’ Diné supermarkets. Founded in 1932, Bashas’ has a rich history of serving Arizona families with quality products and great customer service. With more than 110 grocery stores, Bashas’ is one of the largest employers in the state and we are committed to nourishing the communities we serve through purposeful partnerships and giving centered around our vision and purpose of changing the way we eat one plate at a time.

Shared values led Bashas’ to join The Raley’s Companies in 2021 and the partnership has enhanced our core business through technological advancements, shared learning, leadership development and new offerings. With more than 21,000 team members, we are united by a higher purpose: to deliver quality offerings, exceptional service, and to do right by our people, communities, and planet.

Whether through our commitment to nutrition and wellness or Bashas’ legacy of giving back over $100 million to local communities, we strive to empower customers with transparency, education, and access to fresh, affordable, and nourishing food. We’re looking for the same kind of passionate people to join our team, grow with us and share our purpose.

Position Overview

Are you a seasoned construction leader who thrives on bringing complex projects to life—from initial design through ribbon‑cutting? As a Sr Manager, Construction, you’ll oversee all phases of new store builds and remodels, ensuring projects are completed on time, on budget, and in alignment with company standards and regulatory requirements.

In this role, you’ll lead construction project management staff, coordinate architects and engineers, direct vendor and contractor activity, and serve as the authority on construction methods, materials, and quality. You’ll play a critical role in guiding strategic construction functions that support the company’s growth and long‑term business goals.

If you enjoy balancing fieldwork with project planning, coaching high‑performing teams, and ensuring flawless execution, this is an excellent opportunity to make a measurable impact.

What You’ll Do

Leadership & Team Management

• Oversee and develop construction project management staff, including hiring, coaching, performance evaluations, and handling disciplinary matters.
• Provide clear direction and approval of subordinates’ work to ensure quality and adherence to standards.
• Respond to inquiries from internal leaders, vendors, and external partners; interpret policy, provide documentation, resolve discrepancies, and address complex challenges.

Construction Project Execution

• Manage store construction projects from design phase through construction and warranty period.
• Ensure high‑quality construction, adherence to drawings and specifications, and effective job‑site coordination.
• Lead construction meetings, oversee building and FF&E delivery schedules, and address project‑related questions for seamless execution.

Construction Operations & Oversight

• Oversee bid package development, general contractor selection, contract development, and coordination meetings.
• Maintain comprehensive project files and documentation.
• Review financial reports, approve progress payments, verify lien releases, review billing, and generate punch lists.
• Develop and coordinate construction schedules aligned with merchandising timelines, fixture installation, refrigeration schedules, vendor activity, and contractor requirements.

Design Coordination & Regulatory Compliance

• Partner with Store Design Teams to review budgets, plan layouts, and ensure construction specifications and drawings meet accuracy, code compliance, and company standards.
• Work with local, state, and federal agencies to secure construction permits, including planning, building, fire, health, ADA, and air quality compliance.

Budgeting, Procurement & Cost Management

• Develop and manage blueprint and final estimates related to building and FF&E costs.
• Collaborate with purchasing to coordinate equipment orders, vendor services, materials, and contract services based on final project estimates.

Project Closeout

• Manage project closeout by compiling accurate “As Built” drawings, archiving specifications, and completing project maintenance manuals.
• Review documentation for completeness and accuracy to ensure a smooth transition into ongoing operations.

What You Bring

Education & Experience

• Bachelor’s degree in Construction Management, Business, Engineering, or related field; or equivalent experience.
• 5–7 years of grocery store ground-up builds or grocery store remodel experience

Knowledge & Expertise

• Strong leadership ability with experience coordinating multiple projects, resources, and stakeholders.
• Advanced knowledge of construction concepts, building trades, and building code compliance.

Skills & Strengths

• Strong analytical capability with the ability to draw sound conclusions and support data‑driven decisions.
• Excellent communication skills with the ability to partner with staff, corporate personnel, contractors, property owners, vendors, governmental agencies, and other stakeholders.
• Skilled presenter able to influence and persuade audiences at various levels.
• Strong technical aptitude, including advanced project management skills.
• Deep understanding of federal, state, and local construction requirements.
• Exceptional planning, prioritization, and organizational skills.
• Ability to maintain strong working relationships and foster collaboration throughout the project lifecycle.

Physical Demands

You may occasionally experience:

• Driving to job sites
• Keyboarding and computer work
• Viewing detailed plans on monitors
• Site inspections requiring climbing, reaching, or navigating confined or elevated spaces

Work Environment

This role operates in both a business office environment and active construction sites throughout California, Nevada, Arizona, New Mexico, and four tribal lands.

Duties may require walking, standing, climbing ladders, and frequent site visits for inspections and project oversight.

The above statements are intended to describe the general nature and level of work being performed by people assigned to this job. They are not intended to be an exhaustive list of all responsibilities, duties and skills required of personnel so classified.

Roebuck Landscaping is hiring a Project Manager, Commercial Landscape Construction to lead projects from kickoff through closeout. This role is responsible for coordinating field operations, managing schedules and budgets, supporting crews and subcontractors, and ensuring work is delivered safely, efficiently, and to Roebuck Landscaping standards.

You’ll work closely with Landscape Construction leadership while building strong relationships with Foremen, field teams, subcontractors, general contractors, and clients. We’re looking for someone who can lead, solve problems quickly, and keep projects moving.

Critical Requirement

Must-Have Experience: 3+ years managing commercial landscape construction projects. Candidates without direct landscape construction experience will not be considered. This is not a general construction PM role and not a residential landscaping role.

What You’ll Do

• Manage commercial landscape construction projects from startup to completion
• Coordinate schedules, labor, materials, equipment, and subcontractors
• Monitor jobsite progress, quality, safety, and production
• Track labor, costs, change orders, and project documentation
• Work closely with Foremen and crews to drive execution
• Communicate with clients, GCs, and project partners throughout the job

What You Bring

• 3+ years of direct commercial landscape construction project management experience
• Strong knowledge of hardscape, irrigation, grading, and large-scale plant installation
• Ability to read landscape plans, civil drawings, grading plans, and irrigation specs
• Experience managing multiple projects while maintaining schedule, budget, quality, and safety
• Familiarity with Aspire, LMN, Boss, or similar construction/job costing software
• Strong leadership, communication, and field problem-solving skills

Why Roebuck Landscaping

Roebuck Landscaping is in a powerful season of growth. What began as a respected regional landscape company has rapidly evolved into a scaling platform built to lead the commercial landscape construction industry for years to come.

Our Vivid Vision is clear. Build exceptional projects, develop exceptional people, and create an organization where operational excellence and strong leadership drive long term success. We are assembling a team of high performers who want to grow with the company, take ownership of their work, and play a role in building something meaningful.

We operate by five Core Values that guide everything we do: Integrity, Excellence, Teamwork, Determination, and Passion. These are not words on a wall. They are standards that show up every day in how we lead projects, support our teams, and deliver for our clients.

Before You Apply

Please apply only if your background includes commercial landscape construction project management. If your experience is primarily general construction, residential landscaping, or maintenance, this role will not be the right fit.

Introduction

At Fluor, we are proud to design and build projects that make a meaningful impact in the communities we serve. As part of our team, you will help deliver solutions with safety, quality, and integrity as core priorities.

Summary

The Construction Engineer supports field engineering activities for large infrastructure projects, providing technical expertise in planning, execution, and problem-solving during construction. This role works closely with project management, engineering, and construction teams to ensure design requirements, specifications, and project objectives are met safely and efficiently.

The position focuses on infrastructure related scopes such as civil works, earthworks, utilities, structural concrete, roads, bridges, drainage, and site development.

Job Requirements

• Bachelor’s degree in Engineering (Civil, Structural, Construction, or related) is required.
• Provide field engineering support to construction teams, including interpreting drawings, specifications, and design requirements.
• Support installation planning, sequencing, and work package development for infrastructure construction activities.
• Coordinate with engineering, construction supervision, subcontractors, and field teams to resolve technical issues.
• Assist with quantity tracking, progress measurement, and reporting for assigned scopes of work.
• Develop and review construction procedures, method statements, and technical documentation.
• Verify field installation aligns with engineering documents, quality requirements, and applicable codes.
• Participate in design reviews and provide constructability input.
• Support troubleshooting, field changes, and requests for information.
• Monitor construction activities to ensure adherence to safety and environmental standards.
• Maintain accurate records, logs, and engineering documentation supporting project execution.

Other Requirements

• Ability to work on active construction sites, including outdoor and heavy civil environments.
• Willingness to support extended site assignments as required by the project.
• Strong commitment to safety and Zero Harm principles.
• Ability to communicate and collaborate with multidisciplinary teams in fast paced project settings.
• Strong organizational and problem solving skills.

Preferred Qualifications

• Three to seven years of construction engineering experience, preferably on infrastructure or heavy civil projects.
• Experience in earthworks, grading, utilities, drainage, structural concrete, or transportation infrastructure.
• Experience working with major EPC or CM firms.
• Familiarity with construction management tools, field engineering software, and quality documentation systems.
• Knowledge of relevant codes, standards, and industry best practices for infrastructure construction.

What We Do:

SMK Services, Inc. (SMK) is a Construction Management and Engineering services consultancy based in Belmont, Massachusetts. Our clients include public agencies, professional engineering firms, general contractors, and subcontractors. We provide services in Project Management, Construction Build Strategy, Scheduling, Engineering Support, Construction Estimating, Claims Analysis and Field Services.

With a growing client base and an expanding range of services, SMK is seeking a Senior Construction Scheduler to join our team in the Greater Boston Area.

Company Culture:

SMK is an exciting, collaborative, supportive environment where we take pride in the work we do and celebrate our collective success. We cultivate a strong sense of community, one where colleagues’ voices are valued, growth is encouraged, and leadership remains open and accessible. As our firm continues to expand, the successful candidate will help shape and strengthen SMK’s culture alongside us.

Opportunities for Growth:

SMK is a growing business that is continually evolving, creating meaningful opportunities for employees to grow alongside the company and advance their careers. We actively encourage and support colleagues in developing their careers in areas of the business and industry that align with their interests and passions. SMK offers ongoing professional development opportunities to broaden employee knowledge and ensure our team stays current with the latest industry practices and innovations.

Why SMK

SMK is intentionally built as a close-knit, highly collaborative team where people genuinely know, trust, and support one another. Our size allows for real relationships, open communication, and a workplace where individual contributions are visible and valued.

We pride ourselves on creating a warm, engaging, and supportive environment, one where experienced professionals can do their best work without bureaucracy or being lost in the crowd. Leadership is hands-on and accessible, collaboration is the norm, and we care deeply about both the quality of our work and the well-being of our team.

At SMK, you’re not just filling a role, you’re joining a group of professionals who respect each other’s expertise, enjoy working together, and are committed to growing the firm thoughtfully and sustainably.

The Role:

SMK is seeking a seasoned Senior Construction Scheduler to support and lead scheduling efforts for complex infrastructure and heavy civil design and construction projects, which may include transportation, rail, facilities, multi-modal, and large highway programs. The successful candidate will bring advanced Critical Path Method (CPM) scheduling expertise, deep hands-on experience with Primavera P6, and a proven ability to develop schedules and analyze, manage, and communicate schedule risks, constraints, and construction sequencing.

Ideal Candidate

The ideal candidate is someone who enjoys being trusted to take ownership of their work and is comfortable operating without heavy oversight. They are naturally curious, ask the right questions early, and think several steps ahead when developing or reviewing schedules.

They have the confidence to challenge assumptions, respectfully and constructively, and are comfortable explaining schedule logic, risks, and impacts to both technical and non-technical audiences. Rather than simply updating schedules, they focus on understanding why activities move, where risk is accumulating, and how decisions affect the overall program.

The ideal candidate values clarity, accuracy, and professionalism in written communication and takes pride in producing narratives and analyses that stand up to scrutiny. They are organized, pragmatic, and calm under pressure, with the judgment to prioritize what truly matters when multiple deadlines compete.

Finally, the ideal candidate is someone who appreciates working in a small, close-knit team. They are generous with their knowledge, supportive of colleagues, and motivated by contributing to a respectful, collaborative environment where people genuinely enjoy working together.

Key Responsibilities:

In this role, you will be responsible for a variety of tasks, including:

• Develop, maintain, and manage cost and resource-loaded CPM schedules using Primavera P6 and other scheduling tools.
• Prepare, update, and maintain design and Contract Time Determination schedules in accordance with contract requirements, client procedures, and industry best practices.
• Review designer and contractor schedule submittals, including baseline and re-baseline schedules, monthly updates, Time Impact Analyses, acceleration schedules, and recovery plans, for contractual and technical compliance.
• Perform independent time-impact analyses and review contractor requests for time extensions and delay-related submissions.
• Analyze schedule progress, critical paths, float consumption, and forecasted completion; identify at-risk activities and recommend mitigation strategies.
• Conduct site visits to active heavy civil construction projects to verify progress, document conditions, and perform or review schedule updates.
• Perform “what-if” schedule scenarios to assess impacts to milestones and overall project delivery.
• Prepare clear, well-documented technical reports, narratives, charts, and graphics summarizing schedule analyses and findings.
• Provide quality review of schedule-related reports prepared by others.
• Attend and participate in client progress and scheduling meetings; confidently present schedule updates, analyses, and recommendations.
• Coordinate closely with project managers, designers, contractors, and internal teams to resolve schedule issues and support effective project delivery.
• Support the maintenance and updating of SMK’s company-wide project and program schedules.

Key Attributes:

• Exceptional written, verbal, and organizational skills.
• Demonstrated proficiency in independently authoring clear, well-structured analytical reports and narratives.
• Ability to work independently while also collaborating effectively within a team.
• Strong, intuitive understanding of construction principles, sequencing, and contractor means and methods.
• Professional judgment and confidence to step into client-facing discussions.
• Flexibility with work location within Eastern Massachusetts.
• Willingness to step outside the core role to assist with periodic Project Management tasks as needed.

Qualifications:

A minimum of 6+ years of active civil (heavy) construction scheduling experience (transportation experience preferred), including:

• Developing and updating Contract Time Determination schedules with narrative reports.
• Reviewing and analyzing baseline schedules and monthly progress update schedules developed by others.

Required proficiency in:

• Primavera P6
• Microsoft Excel, Word, and Outlook

Experience with:

• Microsoft PowerPoint
• Bluebeam

Valid driver’s license and access to a personal vehicle

Authorization to work in the United States

Additional Employment Information:

• Full-time salaried position.
• Annual starting salary of $130,000 to $175,000, dependent on experience.
• Paid Time Off.
• Eleven days of holiday pay.
• Generous retirement plan contribution.
• Paid office parking.
• Cell phone allowance.
• Medical and dental insurance.
• Hybrid work structure with remote and in-office days based on workload, collaboration needs, client meetings, training, and experience level.
• Primary work location is office-based, with occasional site visits throughout New England.

Note to Applicants

This is a senior-level role requiring significant experience in Civil (Heavy) Construction scheduling, with Transportation experience preferred. We encourage applicants who closely match the qualifications outlined above to apply. Candidates whose experience does not align with the requirements will not be considered at this time.

Equal Employment Opportunity Statement:

SMK provides equal employment opportunity in employment and advancement for all persons regardless of race, religion, color, national origin, sex, sexual orientation, gender identity, age, status as a protected veteran and persons with a disability, at all employment levels, including the executive level. We do not and will not discriminate against any applicant or employee regardless of race, religion, color, national origin, sex, sexual orientation, gender identity, age, status as a protected veteran and persons with a disability for any position for which the applicant or employee is qualified. Such affirmative action shall apply to all employment practices, including, but not limited to hiring, upgrading, demotion or transfer, recruitment, recruitment advertising, layoff or termination, rates of pay or other forms of compensation, and selection for training, including apprenticeship and on-the-job training.

Project Manager (Mechanical Construction)

Driven by Vision | Powered by Passion

Location: Portland, OR area

Company Overview: Working for global leaders in the aerospace, chemical, steel, pharmaceutical, oil & gas, power generation, and semiconductor industries, BMWC builds facilities that deliver critical products to consumers across the globe. BMWC is a dynamic and forward-thinking construction company. We pride ourselves on being among the most progressive and innovative companies in our field. Our work is fast-paced, diverse and involves projects within rapidly evolving industries. BMWC executes some of the most complex and critical projects in the construction industry. We are passionate about what we do, and we’re looking for a skilled Project Manager to join our team. If you share our passion for executing large, complex, and fast-paced construction projects for customers within rapidly expanding industries, BMWC has an opportunity for you.

Position Summary: As a Project Manager, you’ll play a crucial role in leading and executing construction projects. You will be responsible for managing the development and execution of complex mechanical construction projects ranging from $5M to $30M in direct-hire construction. Leading a team of experienced professionals, you will be responsible for delivering safe projects on time and within budget. If you thrive in a challenging environment and are ready to contribute to our success, we want to hear from you!

Responsibilities:

• Project Planning and Execution:
• Develop and manage project plans, set milestones, and allocate resources effectively.
• BMWC is a self-perform contractor; you will work directly with craft supervision throughout the project lifecycle.
• Monitor project progress, identify risks, and implement corrective actions.
• Execute company safety standards, incentives, and compliance programs.
• Strategic contract management, including commercial terms and craft labor agreements.
• Budget and Cost Management:
• Prepare, manage, and forecast project costs, budget, and overall profitability.
• Monitor and analyze expenses and costs, including labor, material, and equipment.
• Prepare project status reports for BMWC’s leadership team and clients.
• Stakeholder Communication:
• Provide updates for all project phases with necessary stakeholders, including due dates, impacts, and adjustments during the life of the project.
• Liaison and collaborate with clients, subcontractors, and internal teams, proactively following up on requests or issues as needed.
• Client Management:
• Participate in activities/events that promote strong client relationship building.
• Work with the Marketing and Sales Department to pursue new client opportunities, develop proposals, and win new work.
• Team Leadership:
• Lead project teams, motivate team members, and foster a positive work environment.
• Mentor younger employees and prepare them for the next steps in their careers, aligning with BMWC’s core value of “People”.
• Resolve conflicts and facilitate effective communication.

Qualifications and Experience:

• Bachelor’s degree in Construction Management, Engineering, or related field.
• Minimum of 8 years of experience managing industrial construction project teams.
• Proficiency in project management software (e.g., Primavera, Procore, Microsoft Project).
• Strong leadership, communication, and problem-solving skills.
• Demonstrated proficiency in leading and managing cross-functional team members responsible for project controls, estimation, purchasing, safety, quality, and virtual design.

Benefits: We offer one of the best and most comprehensive benefits packages in the industry, as our commitment to employee well-being is critical to our company’s success. Our benefits include day 1 medical coverage and 100% 401K vesting with company match, annual bonuses and profit sharing, and MUCH MORE!

As one of the premier specialty construction companies in the country, our employees enjoy a focus on growth and development, work/life balance, and one of the best safety records in the industry. We are 100% management-owned, making our employees' development and advancement paramount to our success.

Join BMWC Constructors and be part of a team that’s shaping the future of construction!

Construction Practice Leader – Baseline Building Group/Level Workforce

About Level Workforce, LLC

Level Workforce is an innovative consulting and workforce solutions agency dedicated to empowering businesses and business owners in the construction, real estate and finance industries. With over 25 years of combined industry experience, we are passionate about helping clients achieve their goals through strategic guidance, streamlined processes, and operational excellence.

Our team of seasoned professionals offers a range of consulting services, from business advisory to executive hands-on consulting, and staffing solutions to help develop tailored solutions that address our client's unique challenges and goals. We take a client-first approach and prioritize communication, collaboration, and transparency to ensure that our clients feel supported throughout their engagement with us.

THE LEVEL WORKFORCE MISSION

To help businesses build, optimize, and lead their operations. We are committed to providing strategic guidance, streamlining processes, and improving operational efficiency to help our clients thrive in a rapidly changing business landscape. We are committed to helping our industry modernize by implementing automations, sharing our expertise, and facilitating cultural and organizational changes.

Position Details

· Title: Construction Practice Leader – Baseline Building Group/Level Workforce

· Type: 1099 Contract

· Location: 100% Remote

· Hours: 15–20 hours per week

· Experience Level: 10+ years preferred

· Reports To: CEO

Position Overview

Level Workforce is seeking a seasoned construction leader to serve as Director of Construction Operations while leading Baseline Building Group, our affiliated design-build construction platform.

This is a unique opportunity to operate inside an integrated real estate development and construction ecosystem supporting projects led by Creek Stand Land Company along with select commercial clients.

Rather than chasing speculative work, this role focuses on execution, leadership, and operational excellence within a curated project pipeline.

Core Responsibilities

Responsibilities include:

• Leading construction operations consulting for Level Workforce clients • Providing fractional operational leadership to construction businesses • Serving as Business Unit Leader of Baseline Building Group

• Overseeing design-build construction and site work programs • Managing project delivery, financial performance, and team development • Collaborating with development leadership on strategic projects

This role is ideal for:

• Former construction business owners • Senior operations leaders in general contracting or development • Builders seeking pipeline stability and reduced risk while remaining entrepreneurial

Flexible compensation structure available including hybrid hourly, monthly leadership retainer, and performance-based income. Both 1099 and W2 structures may be available depending on the candidate.

Join a fast-moving team building a town-and-country development platform spanning real estate, construction, hospitality, and advisory services.

Qualifications

· Bachelor’s degree in Construction Management, Civil Engineering, Architecture, or a related field.

· 10+ years of experience in commercial construction.

· Career progression through roles such as:

· Project Manager → Senior Project Manager

· Preconstruction Manager

· Operations Manager / Director / VP within a commercial general contractor

· Demonstrated expertise in:

· Preconstruction and estimating

· Comprehensive project management across all phases

· Job costing, cost reporting, and financial controls

· Coordinating field operations and administrative processes

· Managing projects typically in the $2–$5 million+ range

· Experience managing teams, either in a hard-line or dotted-line structure.

· Proficiency in Microsoft Project.

Preferred Experience

· Facilities maintenance exposure

· Real estate development experience

· Owner’s representative or client-side advisory work

Benefits of Working with Level Workforce

At Level Workforce, we go beyond just providing a job—we offer a platform for growth, independence, and long-term success as a 1099 contractor.

What We Offer:

Flexible Schedule – Take control of your time. Set your own hours and work in a way that best fits your lifestyle and business goals.

Established Brand & Resources – Operate within a trusted brand while maintaining your independence. Leverage our reputation, infrastructure, and tools to accelerate your success.

Professional Growth & Networking – Join a network of experienced professionals, gain mentorship, and access industry insights that can help sharpen your skills and expand your opportunities.

Impact-Driven Work – Work with businesses that need real solutions, positioning yourself as a key partner in their success.

At Level Workforce, we believe in ownership over employment—giving you the tools, flexibility, and support to create something bigger than just a paycheck. If you’re ready to take charge of your career, we’re ready to help you make it happen.

About the Company

At Reconstruction Experts, we excel in in-depth reconstruction work, meticulously handling every detail of the construction plan. From environmental testing and inspections by licensed professionals to addressing potential hidden challenges, we ensure that no stone is left unturned. Our full-service contractor team navigates a broad range of needs including preconstruction, HOA reconstruction, construction defect repair, insurance restoration, hospitality reconstruction, remodels, and apartment reconstruction. Our brand is built on our people, and our people embody our core values of respect, integrity, courtesy, and honesty.

General Description

We are hiring a Constructability Manager to provide senior-level technical leadership on complex reconstruction and capital improvement projects. This role is ideal for an experienced construction professional who specializes in constructability reviews, scope validation, engineering coordination, and risk mitigation.

The Constructability Manager serves as the technical authority between Sales, Engineering, and Operations—ensuring projects are buildable, cost-accurate, and execution-ready before reaching the field.

Benefits:

• Salary $110,000 to $120,000
• Vehicle Allowance, fuel card, phone, laptop provided
• 401(k) with match; medical, dental, vision
• FSA/HSA options; life insurance
• Generous PTO and paid holidays

Key Duties & Responsibilities:

• Lead constructability reviews and forensic analysis of engineering drawings to identify unbuildable designs, scope gaps, and logistical risks.
• Deconstruct construction and repair scopes to optimize sequencing, safety, schedule, cost, and quality.
• Reduce RFIs, change orders, and rework by validating engineering intent against real-world construction methods.
• Partner with Sales and Business Development teams to vet feasibility and provide technical differentiation on complex bids and pursuits.
• Serve as the technical advisor to HOA Boards, Property Managers, Owners, and Clients, translating complex construction issues into clear, actionable plans.
• Lead RFP development and rollout to engineers and trade partners, ensuring scopes are executable and pricing is build-ready.
• Identify value engineering opportunities, alternative construction methods, and cost-saving strategies.
• Collaborate with field leadership to ensure alignment between scope, schedule, budget, and execution strategy.

Key Selection Criteria:

• Bachelor’s degree in Civil Engineering, Construction Management, Architecture, or a related field.
• General Contracting license - Highly Desirable
• 15+ years of experience in construction management, engineering, estimating, or senior project leadership.
• Strong background in constructability analysis, scope development, and engineering coordination.
• Proven experience managing high-stakes client relationships and leading technical meetings.
• Advanced proficiency in Procore, Bluebeam, Microsoft Project, and Microsoft Office.
• Knowledge of construction means and methods, safety regulations, and sequencing.
• Willingness to travel as needed.

Apply Today!

If you are eager to advance your career and enhance your leadership skills, we want to hear from you! The successful candidate must have the right to work in the USA and be prepared for a criminal background check.

JOB PROFILE: REVIT DRAFTER – MODULAR CONSTRUCTION  

The Modular Revit Drafter converts architectural and engineering design drawings into LOD 400 production drawings used directly by our factory production team. This role supports the Modular Design Manager and ensures that modular building units are detailed accurately and efficiently for construction. This is a production drafting role in a high-output modular manufacturing environment. 

WHAT YOU HAVE ALREADY ACHIEVED (Minimum Requirements): 

• Entry Level: Experience with Autodesk Revit or similar BIM software (0-2 years) 
• Entry Level: Drafting support role (experience in any 3D or 2D drawing software) 
• Advanced Level: 2-4 years experience with Autodesk Revit 
• Advanced Level: Independently produced production drawing sets (architectural or structural or MEP) 
• Working knowledge of Revit modeling workflows including views, sheets, and annotation standards 
• Ability to manage multiple drawing updates and revisions in a fast-paced production environment 
• Ability to read and interpret architectural and engineering drawings with an understanding of construction documentation, residential or light commercial framing, and common building assemblies 
• Strong attention to detail and the ability to produce clear, organized construction drawings including dimensions, notes, and schedules 
• Ability to create framing takeoffs from structural and architectural drawings for single family homes 

WHAT SETS YOU APART (Preferred Requirements): 

• Familiarity with modular or prefabricated construction methods. 
• Hands-on construction experience, such as framing, electrical, carpentry, or similar trades (1–2 years preferred) 
• Ability to independently review and interpret residential or commercial building codes 

WHAT YOU ARE GREAT AT (Day-to-Day Responsibilities): 

• Work in a detail-oriented and systematic manner 
• Communicate clearly and professionally via phone and written (email, teams, plans, etc.) with internal and external team 
• Produce detailed shop drawings for modular building units, including wall, floor, and roof framing 
• Prepare production-ready drawings including dimensions, notes, material schedules, and construction details 
• Organize plan sets into individual sheets based on singular mods to be used by the factory production team 
• Create and maintain accurate models in Revit 
• Maintain drawing standards and organization within project models 
• Work closely with the Modular Design Manager to coordinate structural, architectural, and MEP systems within a model 
• Identify potential constructability issues and assist in resolving conflicts before plans are released to production 
• Implement design revisions based on RFIs, production feedback, and design updates 
• Maintain and update drawing sets throughout the project lifecycle 
• Contribute ideas to improve drafting standards and modular workflows 
• Communicate effectively with production staff to clarify drawing information and resolve issues 

YOU THRIVE ON: 

MAKING AN IMPACT. Your work directly shapes communities by delivering high-quality, factory-built housing to developers and homeowners. Whether it’s the families who move into our finished homes, the builders who trust us with their projects, or the internal and external teams that bring it all together – you play a key role in making it happen. 

OVERCOMING CHALLENGES. You see roadblocks as opportunities and proactively find solutions. 

GROWTH & INNOVATION. We’re scaling fast – doubling our manufacturing capacity every six months and working toward opening a 200,000-sf factory that will employ 250 people and build 1,000 housing units per year. If you love being part of a team that’s building something bigger than themselves, this is the place for you. 

WHO WE ARE: 

OUR PURPOSE. To empower people in and impacted by the construction industry to create quality homes, strong communities, and healthy families. 

HOW WE WORK. On time, on-budget delivery – We promise to deliver your modular construction projects on time and within budget, reducing risks and ensuring a faster path to revenue. 

TRANSPARENT COMMUNICATION AT EVERY STEP. From design to delivery, we provide honest, clear, and consistent updates ensuring clients are informed and confident throughout the process. 

CONSISTENT & RELIABLE QUALITY STANDARDS. Our weatherproof, factory-built modules ensure consistent quality and durability, minimizing the risks of traditional construction such as weather and inconsistent workforce.  

A TRUE PARTNERSHIP FOCUSED ON PARTNER SUCCESS. We treat your project as our own, collaborating closely to meet your goals and celebrating milestones like setting day with our clients. 

OUR CORE VALUES: 

POSITIVE ATTITUDE. Action-oriented instead of complaining and proposing solutions instead of expressing pessimism or distrust. Bringing fun to the workplace. 

CLARITY & COMPASSION. Direct and straight forward communication while seeing others as a valuable human being that deserves empathy. 

FOCUS. Approaching work in a systematic way, creating structures that empower others, making sober and data-driven decisions.  

BUILD LIKE IT’S YOUR OWN. Working with purpose and serving our clients with excellence as if you would build the project for yourself. Mediocrity is not an option.  

ALWAYS TEACHING, ALWAYS LEARNING. Committed to consistent growth and generous knowledge sharing.  

SEE THE BEST, BE THE BEST. Seeing the best in every person you engage with (team members, clients, business partners). Believing in others and encouraging them daily.  

SCHEDULE: 

• Full-time in office: Monday through Friday, 8:00 AM – 4:30 PM.  

COMPENSATION AND CAREER GROWTH:

• $60,000 – $90,000 annually depending on experience. 
• Senior BIM designer positions available. Please reach out to our team to learn more. 

BENEFITS AND PERKS (available after 90 days introductory period): 

• 80 hours vacation (accrued annually) 
• 40 hours sick pay per year 
• 5 paid holidays (New Year’s Day, July 4th, Thanksgiving Day, Christmas Eve, Christmas Day) 
• Employer-subsidized medical insurance (health, dental, vision) 
• Employer-paid Life Insurance 
• 401(k) with up to 3.5% corporate match 
• Exclusive employee swag 
• Semiannual All-Team gatherings 

DISCLAIMERS: 

• All job applications shall remain open and valid for a period of 90 days. 
• If you intentionally falsify your application, the Company may terminate the employee.