Marathon Construction And Development Jobs in Usa

Construction Scheduler

Location: Oceanside, CA - Project Based

Position Summary

Cannon Building, a premier general contractor in the life sciences, healthcare, commercial/institutional, and industrial sectors, is seeking a seasoned Scheduler to develop complex life science and healthcare construction projects in the San Diego region. This role ensures schedule accuracy, compliance with regulatory and client requirements, and proactive identification of schedule risks while supporting teams in delivering project on time and within scope.

The ideal candidate is responsible for developing, maintaining, and analyzing detailed project schedules for Life Science and Healthcare constructions projects, including laboratories, clean rooms, pharmaceutical manufacturing facilities, and regulated environments. 

Core Competencies 

• Technical Expertise: Deep knowledge of construction processes specific to life sciences facilities (e.g., labs, pharmaceutical plants, cleanrooms). Familiarity with industry standards like Good Manufacturing Practices (GMP) and Good Laboratory Practices (GLP), and technical systems such as specialized HVAC systems and lab utilities.
• Regulatory Compliance: In-depth understanding of life sciences regulatory requirements (FDA, OSHA, ISO), particularly Environmental Health and Safety (EHS) standards for life science facilities. Proven ability to manage compliance in cleanrooms, labs, and containment areas.
• Risk Management: Skilled in conducting detailed risk assessments for life sciences projects, with experience in biosafety and environmental standards. Proficient in creating and executing contingency plans for risk mitigation.
• Technical Software Skills: Able to interpret Building Information Modeling (BIM)

Responsibilities

Project Planning and Coordination:

• Plan, coordinate, and manage project submittals and schedules to align with overall project construction.
• Prepare, monitor, and update the project schedule, coordinating with the Superintendent’s schedules and documenting delays. Establish and integrate material delivery schedules.
• Develop and maintain integrated project schedules using Primavera P6 (or similar scheduling software) for Life Science and Healthcare construction projects.
• Perform schedule updates, progress tracking, and variance analysis on a regular basis.
• Identify critical path activities, schedule risks, and mitigation strategies.
• Create Time Impact Analysis documents and effectively present information to clients and other stakeholders.

Financial Management:

•  Participate in the end-of-month financial reviews, assessing the budget and reporting the project’s completion status.

• Verify subcontractor billings as requested related to billed progress.

Leadership and Communication:

• Provide leadership through effective communication with owners/clients, architects, consultants, and the project team, fostering teamwork among all stakeholders.

• Collaborate with Project Managers, Superintendents, Engineers, and subcontractors to establish realistic sequencing, durations, and logic.

• Organize and lead project schedule review meetings, prepare minutes and ensure all parties understand and fulfill their obligations.

Contract and Compliance Management Knowledge:

• Deep understanding of life sciences regulatory standards (FDA, OSHA, Local regulatory agencies) and how non-compliance risks can impact construction projects.

• Experience with Environmental Health and Safety (EHS) standards specific to life sciences facilities, including cleanrooms, lab spaces, and containment areas.

•Familiarity with ISO standards applicable to life sciences facilities.

Quality and Safety Assurance:

•Manage project closeout procedures, including monitoring punch list completion and preparing warranties and operations manuals.

• Support project closeout by tracking substantial completion, commissioning, and final turnover milestones.

Travel Requirements:

• Travel may be required; the position is based out of the San Diego region, with travel needed for jobs across the company as well as for meetings at our corporate location in Placentia or other areas as required.

Qualifications and Requirements

• Educational Background: Four-year college degree/Bachelor of Science Degree preferred.
• Experience Requirement: Minimum of 5+ years of experience in construction scheduling experience, preferably in Life Sciences, Healthcare, or high0tech facilities.
• Ability to work in a fast-paced, deadline-driven environment
• Proficiency in Primavera P6 (required) OPC experience a plus. Experience with MS Project a Plus
• Technical Software Skills: Familiarity with Building Information Modeling (BIM) for identifying and addressing potential construction risks early in the design phase.
• Must possess a solid understanding of construction design, technical equipment, and quality systems
• Technical Expertise: Deep knowledge of construction processes for life science facilities (e.g., laboratories, pharmaceutical manufacturing plants, cleanrooms).
• Familiarity with life sciences industry standards, including Good Manufacturing Practices (GMP) and Good Laboratory Practices (GLP).
• Understanding of building systems specific to life sciences (e.g., HVAC for cleanrooms, lab design, specialized utilities).
• Strategic thinking and informed decision-making skills, with the ability to analyze project requirements, assess risks, and develop effective strategies to meet project goals. Proactive problem-solving approach.
• Excellent Written and Communication Skills: Candidate must possess excellent written and verbal communication skills, enabling effective interaction with clients, stakeholders, senior executives, and team members. Strong presentation and negotiations skills to manage client expectations, resolve conflicts, and influence project outcomes.

Who We Are:

Cannon Building is a leading Life Science, Commercial/Institutional, Healthcare, and Industrial builder, providing highly efficient, cost-effective construction solutions with a commitment to safety and an uncompromising standard of quality. Cannon Building is proud to be a family-owned business, celebrating its 30th year in operation. We empower our employees to take the lead in achieving their own, unique goals. Our company culture is one of teamwork, inclusiveness, growth, leadership and creativity.

We respect and rely on one another for exceptional results. We promote an environment of collaboration, enjoy working together, and celebrate the success of our clients, knowing that customer success is the basis for our long-term success. To learn more about our work culture, visit our Company Website.

Our Mission: To develop long-term working relationships by providing premier commercial construction services.

Our Vision: To efficiently deliver quality projects with the highest level of customer satisfaction.

Our Values: We are professional, ethical, innovative, and accountable.

Seeking a flexible, detailed oriented team player with the ability to manage multiple tasks, produce quality work, and consistently meet deadlines. Proven expertise in healthcare with a strong network of industry contacts. Experience in Life Sciences, Construction, or similar fields is beneficial.

Compensation:

Salary: $105k - $145k

Offers a competitive compensation package that includes a 401(k) plan with match: employee group dental, vision, life, and disability. Medical insurance, family dental and vision insurance, and supplemental life insurance available with reasonable employee contributions; paid holidays, vacation, and sick time; FSA 

Project Manager (Mechanical Construction)

Driven by Vision | Powered by Passion

Location: Portland, OR area

Company Overview: Working for global leaders in the aerospace, chemical, steel, pharmaceutical, oil & gas, power generation, and semiconductor industries, BMWC builds facilities that deliver critical products to consumers across the globe. BMWC is a dynamic and forward-thinking construction company. We pride ourselves on being among the most progressive and innovative companies in our field. Our work is fast-paced, diverse and involves projects within rapidly evolving industries. BMWC executes some of the most complex and critical projects in the construction industry. We are passionate about what we do, and we’re looking for a skilled Project Manager to join our team. If you share our passion for executing large, complex, and fast-paced construction projects for customers within rapidly expanding industries, BMWC has an opportunity for you.

Position Summary: As a Project Manager, you’ll play a crucial role in leading and executing construction projects. You will be responsible for managing the development and execution of complex mechanical construction projects ranging from $5M to $30M in direct-hire construction. Leading a team of experienced professionals, you will be responsible for delivering safe projects on time and within budget. If you thrive in a challenging environment and are ready to contribute to our success, we want to hear from you!

Responsibilities:

• Project Planning and Execution:
• Develop and manage project plans, set milestones, and allocate resources effectively.
• BMWC is a self-perform contractor; you will work directly with craft supervision throughout the project lifecycle.
• Monitor project progress, identify risks, and implement corrective actions.
• Execute company safety standards, incentives, and compliance programs.
• Strategic contract management, including commercial terms and craft labor agreements.
• Budget and Cost Management:
• Prepare, manage, and forecast project costs, budget, and overall profitability.
• Monitor and analyze expenses and costs, including labor, material, and equipment.
• Prepare project status reports for BMWC’s leadership team and clients.
• Stakeholder Communication:
• Provide updates for all project phases with necessary stakeholders, including due dates, impacts, and adjustments during the life of the project.
• Liaison and collaborate with clients, subcontractors, and internal teams, proactively following up on requests or issues as needed.
• Client Management:
• Participate in activities/events that promote strong client relationship building.
• Work with the Marketing and Sales Department to pursue new client opportunities, develop proposals, and win new work.
• Team Leadership:
• Lead project teams, motivate team members, and foster a positive work environment.
• Mentor younger employees and prepare them for the next steps in their careers, aligning with BMWC’s core value of “People”.
• Resolve conflicts and facilitate effective communication.

Qualifications and Experience:

• Bachelor’s degree in Construction Management, Engineering, or related field.
• Minimum of 8 years of experience managing industrial construction project teams.
• Proficiency in project management software (e.g., Primavera, Procore, Microsoft Project).
• Strong leadership, communication, and problem-solving skills.
• Demonstrated proficiency in leading and managing cross-functional team members responsible for project controls, estimation, purchasing, safety, quality, and virtual design.

Benefits: We offer one of the best and most comprehensive benefits packages in the industry, as our commitment to employee well-being is critical to our company’s success. Our benefits include day 1 medical coverage and 100% 401K vesting with company match, annual bonuses and profit sharing, and MUCH MORE!

As one of the premier specialty construction companies in the country, our employees enjoy a focus on growth and development, work/life balance, and one of the best safety records in the industry. We are 100% management-owned, making our employees' development and advancement paramount to our success.

Join BMWC Constructors and be part of a team that’s shaping the future of construction!

Company Description

Cannon Building, a leading general contractor specializing in life science, healthcare, commercial/institutional, and industrial sectors, is seeking an experienced Superintendent to oversee and drive the successful delivery of healthcare construction projects in the San Diego area.

As a Superintendent at Cannon Building, your primary focus will be the Cannon Building’s Safety Plan at the jobsite. Work with the Project Manager to develop a project schedule. Monitor with and assist the Project Manager in the execution of the project financial goals. Provide quality control by studying drawings, questioning uncertain details, continuously walking the job and inspecting each trades work and compare it to the contract documents. Be a problem solver prior to the work taking place and ensure that the work meets or exceeds the requirements of the contract documents.

Role Description

This is a full-time, on-site role for a Construction Superintendent – Life Science at Cannon Building. Based in Carlsbad, CA, the Construction Superintendent will oversee daily on-site operations of construction projects, ensuring they are executed on time, within budget, and meet quality and safety standards. Responsibilities include managing crews and subcontractors, ensuring compliance with safety protocols, preparing and following project schedules, and coordinating resources and materials to optimize efficiency. The role requires collaboration with project management teams and maintaining clear communication with stakeholders.

Responsibilities:

Project Planning and Coordination:

•  Monitor and document all SWPPP, BMP and storm related paperwork related to the project including job surveys and updating of the SWPPP plans and keeping all files up to date.

Leadership and Communication:

•  Provide leadership by using effective verbal and written communications to manage the subcontractors and field personnel as well as interact with the Owner, Architect and Consultants on behalf of the company.
• Organize and lead project meetings, prepare minutes, and ensure all parties understand and fulfill their obligations.

 Contract and Compliance Management:

• Ensure compliance with general conditions and contract requirements, monitoring contract documents for conformance and execution.
• Negotiate subcontract and purchase order terms, oversee subcontract execution, and manage subcontractor claims.

 Project Documentation and Systems:

• Utilize Procore to manage project documentation and costs, overseeing the preparation and reporting of RFIs, submittals, inspections, safety reports, change orders, and related documents.
• Confirm all contracts are signed and insurance is in place prior to allowing any personnel on the jobsite to perform any work. Reads and has a working knowledge of subcontracts and change orders. Review weekly project logs for insurance, RFIs, Submittals, and Material Delivery Logs to ensure the proper delivery of materials, equipment and labor to the project.
• Review shop drawings along with Project Manager to help ensure compliance with the construction documents.

Quality and Safety Assurance:

• Participate in Operations and Safety meetings, promoting and enforcing jobsite safety.
• Start up the project assessing safety requirements and site logistics. Schedule and document safety start up meetings with the subcontractors reviewing Cannon Building’s safety requirements, OSHA requirements, Site Specific Safety requirements and reporting requirements.
• Monitor work quality and perform regular inspections to ensure construction standards are consistently met.
• Enforce strong safety culture, conducting regular safety meetings, inspections, and ensuring compliance with OSHA and other safety regulations.

Travel Requirements:

•  Travel may be required; the position is based out of the San Diego region, with travel for projects as needed in Orange, Los Angeles, or San Diego counties.

Qualification and Requirements

Experience Requirement: Demonstrates a working knowledge of commercial construction with a minimum of five years of experience in this area with a focus on Life Science and Pharmaceutical

· Education/Training: Bachelor’s degree in construction management, Civil Engineering, or a related field preferred. Additional certifications in OSHPD/HCAI regulations and construction safety are a plus

· Experience as Lead Superintendent for Life Science/Pharmaceutical projects

Project Experience: Project experience valued at $2 Million or greater as a Superintendent.

• Minimum of 5 previous project experience managing Life Science/ Pharmaceutical

Excellent Written and Communication Skills: Candidates must possess excellent written and verbal communication skills, enabling effective interaction with clients, stakeholders, team members, and other project participants. Strong presentation and negotiation skills are essential to manage client expectations and influence project outcomes.

Technical Expertise: In-depth understanding of construction techniques, including reinforced concrete, wood framing methods, and engineering details, as well as electrical, mechanical, and plumbing systems.

Technical Proficiency: Proficient computer skills in Microsoft Office Suite, project management software

(Procore or similar), scheduling software (MS Project or similar), PDF management (Bluebeam), and BIM software (AutoCAD, Revit, Navisworks, or similar).

Strategic and Analytical Thinking: Ability to think strategically and make informed decisions, including analyzing project requirements, assessing risks, and developing effective strategies to meet project goals. Proactive approach to problem-solving.

Financial Management: Advanced skills in budgeting, financial management, and cost control, including developing and monitoring project budgets, tracking expenses, and ensuring financial objectives are met. Experience in managing project contracts and subcontractors.

Risk Management: Deep understanding of risk management principles and techniques, including identifying potential risks, developing risk management strategies, and implementing mitigation plans to minimize project disruptions.

 Quality Assurance: Strong focus on quality control and assurance, ensuring compliance with relevant codes, standards, and specifications. Experience in conducting quality audits and implementing quality control measures.

Client Management: Maintains good working relationships with City Officials and Inspectors. Schedules all City Inspections in advance to ensure schedule commitments are met.

Who We Are:

Cannon Building is a leading Life Science, Commercial/Institutional, Healthcare, and Industrial builder, providing highly efficient, cost-effective construction solutions with a commitment to safety and an uncompromising standard of quality. Cannon Building is proud to be a family-owned business, celebrating its 30th year in operation. We empower our employees to take the lead in achieving their own, unique goals. Our company culture is one of teamwork, inclusiveness, growth, leadership and creativity.

We respect and rely on one another for exceptional results. We promote an environment of collaboration, enjoy working together, and celebrate the success of our clients, knowing that customer success is the basis for our long-term success. To learn more about our work culture, visit our Company Website.

Our Mission: To develop long-term working relationships by providing premier commercial construction services.

Our Vision: To efficiently deliver quality projects with the highest level of customer satisfaction.

Our Values: We are professional, ethical, innovative, and accountable.

Seeking a flexible, detailed oriented team player with the ability to manage multiple tasks, produce quality work, and consistently meet deadlines. Proven expertise in healthcare with a strong network of industry contacts. Experience in Life Sciences, Construction, or similar fields is beneficial.

Compensation:

Salary: $120k to $160k DOE

Offers a competitive compensation package that includes a 401(k) plan with match: employee group dental, vision, life, and disability. Medical insurance, family dental and vision insurance, and supplemental life insurance available with reasonable employee contributions; paid holidays, vacation, and sick time; FSA

ABOUT US

Oakley Real Estate Partners (OREP) is an Atlanta based full service commercial real estate company founded in 2024. Our mission is to provide top-quality customer service and exceptional results for our clients and investors. We achieve this through unmatched market knowledge, established relationships, and unwavering integrity. Our team is dedicated to bringing attention to detail, creativity, precision, and grit to every transaction. With over $3 Billion in brokerage transaction volume and more than $1 Billion in successful investments, Oakley Real Estate Partners brings extensive experience and a proven track record to every project.

Under the Oakley Real Estate Partners (“OREP”) umbrella there are two companies: the brokerage and third-party services vertical, Oakley Brokerage Partners, LLC (“OBP”) and the principal investment and development vertical, Oakley Capital Partners, LLC (“OCP”). Director of Development will primarily work under OCP, but will have opportunities to participate in OBP activities, including sourcing/executing third-party construction management assignments, and assisting in potential brokerage disposition opportunities.

OCP TRACK RECORD

In our first full calendar year, OCP acquired 220,000 SF across ten transactions totaling over $40M in value, including a speculative land transaction which was converted to a BTS for a large commercial appliance manufacturer. We currently have five active deals under contract totaling $47M in value including two ground up development sites, and a growing pipeline following.

________________________________________________________________________________

TITLE: DIRECTOR OF DEVELOPMENT

Location: Atlanta, Georgia

Reports to: Principal of OCP, Hayes Brewer

Position: Full-time in office or on jobsites

POSITION SUMMARY

The Director of Development will spearhead industrial projects through the full project lifecycle. From site selection and entitlements to completion and turnover. Beyond ground-up builds, this individual will oversee complex value-add repositioning and asset repurposing. We are seeking a seasoned professional with at least five (5) years of direct experience within an industrial general contractor, site contractor, or in-house development construction management team. The Director of Development will be responsible for ensuring projects are delivered on time, within budget, and in accordance with company quality standards. This role is site-intensive and requires presence on active project sites a minimum of four (4) days per week. This is a rare opportunity for an ambitious go-getter to join a rapidly growing, entrepreneurial firm at the ground floor and play a primary role in scaling our development team.

This individual will play a critical role in risk mitigation, cost control, schedule management, contractor oversight, and value optimization, with performance-based bonus opportunities tied to timing and savings realized on managed projects.

KEY RESPONSIBILITIES

Project Leadership & Execution

• Oversee multiple industrial development projects from site selection, entitlements and due diligence to pre-construction through completion.
• Work with local municipalities and zoning authorities to ensure compliance with applicable code
• Manage applicable requirements with civil engineers, project budgets, schedules, and overall execution strategy.
• Ensure projects are delivered on time and within approved budgets.
• Identify and mitigate risks that could impact cost, schedule, leasing flexibility or quality.
• Maintain high standards of construction quality and safety compliance.

On-Site Oversight

• Be physically present on project sites a minimum of four (4) days per week.
• Coordinate daily with engineers, general contractors, subcontractors, inspectors, and consultants.
• Monitor construction progress and proactively address delays or issues.
• Ensure alignment between field operations and ownership objectives.

Budget & Cost Management

• Review and approve project budgets, GMPs, change orders, and pay applications.
• Identify value engineering opportunities without compromising quality.
• Track cost savings initiatives and ensure accurate reporting.
• Maintain disciplined cost controls throughout the project lifecycle.

Pre-Construction Management

• Participate in contractor selection and bid review.
• Lead scope reviews and identify gaps prior to contract execution.
• Collaborate with architects, engineers, and consultants during design phases.
• Ensure constructability reviews are completed thoroughly.

Stakeholder Communication

• Provide regular reporting to OCP Principals.
• Maintain strong working relationships with contractors and consultants.
• Represent the company professionally with municipal officials and third parties.

Qualifications

• Minimum of five (5) years of experience working directly for a general contractor, site contractor or an in-house construction management team for a development company.
• Direct experience managing industrial development projects (warehouse, distribution, light manufacturing, flex, etc.).
• Strong understanding of civil design and civil construction.
• Strong understanding of construction budgets and GMP structures.
• Strong understanding of schedule development and tracking.
• Strong understanding of change order management and value engineering.
• Demonstrated ability to deliver projects on time and on budget.
• Strong field presence and leadership capabilities.
• Excellent communication and negotiation skills.
• Proficient in construction management software and project tracking tools.
• Must be detail oriented, and willing to “get in the weeds,” while maintaining a high-level strategic focus.
• Bachelor’s degree in Construction Management, Engineering, Architecture, or related field.
• General Contracting license or Professional Engineering license preferred but not required.

Performance Expectations

• On-time project delivery.
• Budget adherence and cost savings realized.
• Quality control and minimal rework.
• Effective contractor management.
• Proactive problem solving and risk mitigation.

Compensation & Immediate Incentives

• Competitive base salary commensurate with experience.
• Performance-based bonus tied directly to timing and cost savings realized on managed projects.
• Opportunity for long-term growth within a vertically integrated commercial real estate platform.
• Opportunity to invest in firm activities and ongoing deal flow from Day 1, with no immediate vesting schedule. 

Macro-Z-Technology (MZT) is a leading construction company known for building exceptional projects through an unwavering commitment to its people. With a strong reputation in the Federal and Municipal construction markets, MZT has built everything from roadways and dams to multi-story building construction and complete facility renovations. With an in-house design department, we specialize in design-build projects.

As a Senior Project Manager at MZT, you’ll play a pivotal role in overseeing the successful completion of our largest construction projects. You will be responsible for managing the entire project lifecycle, which includes ensuring adherence to timelines, budget, and quality standards. You’ll interface regularly with the Client, Client stakeholders, and other construction professionals to resolve project challenges. Your strong leadership, organizational skills, and construction expertise will be vital in driving the successful completion of projects that are safe, on-time, within budget, and leave the Client satisfied.

We are looking for Senior Project Managers with experience working on Federal and Civil construction projects (roads/bridges, wastewater/sewer systems, railways, tunnels, dams, airports, etc.). While we appreciate candidates from other construction backgrounds only those with Civil construction experience will be considered.

Company Culture

• MZT covers 100% of the premium for medical, vision, and dental insurance for you and your family because we want you to be well. You won’t find this benefit anywhere else.
• MZT supports professional development. Whatever your growth goals are, we’re here to provide support. We offer an incentive for you to get your PMP or CCM certification within your first six months of joining our team.
• MZT trusts your skills and expertise. We encourage our Construction Project Managers to exercise their judgment, explore innovative approaches, and seize opportunities for growth, while guided by our core values to delivering projects that align with our commitment to excellence.
• Teamwork is at the heart of everything we do. As part of our team, you will be an integral part of a collaborative and supportive environment. We value the power of collective knowledge and believe that together we can achieve remarkable results.
• You’ll work directly with the company owner – your voice will be heard.
• Room for growth? You bet! Over 20% of MZT’s key leaders started in the field.

Key Responsibilities

• Project planning and execution, budgeting and cost control, team leadership and collaboration, and quality assurance and safety compliance on assigned projects.
• Develop project, schedule and monitor project milestones and effectively schedule appropriate employees and contractors (with strong support from the Superintendent) for best quality work in timely fashion.
• Ensure compliance with federal, state, local, industry, contractual, and company regulations, standards, specifications, and best practices.
• Contribute to pre-construction phase including scheduling, constructability review, estimating, bidding, and interfacing with our in-house design department.
• Prepare necessary documentation, such as RFIs, submittals, subcontracts, change orders, etc.
• Serve as primary point of contact for the Superintendent, consultants, contractors, and others as appropriate to each project.
• Effectively motivate and manage in-field managers and subs for timely project completion.
• Lead the buyout process for your assigned project(s). Negotiate with subcontractors.
• Communicate project milestones to stakeholders at regularly scheduled meetings and as needed throughout the project lifecycle.
• Attend all design and construction meetings, such as Post-Award Kickoff (PAK).
• Support the Superintendent in resolving in-field challenges with construction or personnel issues.
• Coordinate building structure as well as related aspects (e.g., mechanical, plumbing, electrical) with subcontractors and related personnel.
• Prepare and present a Monthly Project Review report.
• Certify and sign statement on each invoice that all work to be paid under the invoice has been completed in accordance with contract requirements.
• Perform other duties as assigned.

Qualifications & Experience

• Bachelor’s degree in construction management, civil engineering, building construction, or related field is preferred.
• Minimum 8 years’ experience in construction management overseeing multiple, concurrent projects as a Project Engineer, PM, or equivalent role.
• MUST HAVE proven background in Federal and/or Military construction projects
• Knowledge of the FARS is preferred.
• Knowledge of Federal procedures is preferred.
• EM 385 USACE Certification preferred.
• PMP or CCM certification is preferred
• Experience in both civil/ horizontal and building/ vertical construction
• Demonstrated experience in mid-level construction management on commercial, public works, or government construction projects.
• Communication skills will be subject to assessment in both verbal and written form—business correspondence as well as ad-hoc in-field communication will both be strong demands in this position

Technical Skills

• Proficient in Microsoft Office: Excel, Word, Outlook, Teams, etc.
• Proficient in Primavera P6 (prefer to see certification as well)
• Other construction management platform experience desired (e.g., Procore, RMS, Oracle, eCMS, etc.)

What We Offer

• Salary: $140,000 - $170,000 per year DOE
• Sign On Bonus - $10,000
• Health, dental, and vision insurance premiums 100% paid for you and your dependents
• Life Insurance (100% premium paid by the company for the employee only)
• 401(k) with 100% match up to 4% of salary
• Paid time off
• Opportunity for bonuses based on performance

Schedule

• Full time
• Hours vary, weekend work may be required
• In office or on-site where the project is located
• Must be willing to travel

EEO

We’re dedicated to creating a respectful workplace that values diversity and offers equal employment opportunities for all qualified candidates. We celebrate our diverse team and ensure that every applicant is considered based solely on qualifications, without discrimination. We abide by the requirements of 41 CFR 60-741.5. This regulation prohibits discrimination against qualified individuals on the basis of disability, and requires affirmative action by covered prime contractors and subcontractors to employee and advance in employment qualified individuals with disabilities.

VEVRAA/This contractor shall abide by the requirements of 41 CFR 60-300.5(a). This regulation prohibits discrimination against qualified protected veterans, and requires affirmative action by covered prime contractors and subcontractors to employee and advance in employment qualified protected veterans.

• Receives maps and staking sheets for the full construction project and ensures project is built, with limited guidance from supervisors.
• Communicates updates to the project team as required.
• Manages daily and weekly project work based on deadlines, material and equipment availability, weather, and other factors.
• Coordinates with supervisor to ensure continual supply of work and availability of materials.
• Drafts and submits redlines upon completion of project.
• Ensures locates are performed on time and prior to team and equipment arriving at the worksite.
• Regularly engages municipalities, utility companies, suppliers, contractors, and property owners in order to smoothly coordinate project tasks and avoid disputes.
• Reads construction plans and municipality permits, and determines approach for completing work.
• Maintains all project documentation and records costs of project materials and material transfers.
• Ensures DOT inspections are performed on equipment.
• Works with project managers to ensure projects remain on schedule and within budget.
• Performs general construction labor in various weather conditions while utilizing safety fundamentals.
  • Advanced operation of trenchers, backhoes, end loaders, plows, and other excavating equipment to construct and maintain outside plant cable facilities.
  • Advanced operation of all test equipment associated with outside plant facilities and construction duties.
  • Installs, troubleshoots, tests, splices, repairs, and maintains fiber optic facilities.
  • Identifies location of defective cable using various test equipment and repairs buried, aerial, underground, and/or customer cable.
  • Locates cable and fiber in response to customer requests and/or construction needs.
  • Performs cable fault acceptance tests on newly constructed facilities.
• Actively trains, monitors, and coaches team members while sharing construction knowledge and experience. Performs quality control inspections and makes training recommendations. Ensures safety protocols are enforced.
• Services, cleans, maintains, and repairs equipment.
• Completes all related paperwork in a timely manner.
• Provides assistance to field services technicians, as needed.

• 2+ years of construction equipment operation utilizing various underground and aerial construction equipment such as directional drills, trencher/plow/rock saw, backhoe, or bucket trucks -OR- current military service, or prior military service with honorable discharge.
• 1+ years of experience leading construction projects as a crew foreperson or project manager.
• Must follow the TDS attendance guidelines in order to meet TDS's business needs including but not limited to our obligations to our customers and to our customers' needs.
• Must have and maintain a valid driver's license and remain eligible for DOT requirements.

• Must have the ability to obtain a Class A CDL. A current CDL is preferred at hire, but TDS will train and certify eligible associates through its in-house CDL certification program after hire.
• Physical requirements may vary based on company needs: Ability to climb poles, ladders, towers, and other structures as needed. Ability to kneel, dig, lift, and pull.
• Upon hire, must successfully pass all components of the Safety Training course curriculum.
• Upon hire, must successfully complete customer-specific requirements, which may include a background check administered by the customer.
• Preferred 2+ years' experience in the construction of fiber optic cable outside plant networks -OR- 2+ years installation of any underground or overhead utilities will be considered.
• Understanding of telecommunication products and services.
• Proven organizational skills and ability to multi-task.
• May require occasional travel.
• Must be willing to work overtime as needed. May be required to work various/swing shifts as business needs dictate.
• Must be able to operate vehicles with manual transmissions.

• Medical Coverage
• Dental Coverage
• Vision Coverage
• Life Insurance
• 401(k) Plan
• Generous Vacation & Paid Sick Leave
• Seven Paid National Holidays & One Floating Holiday
• Paid Parental Leave (6 weeks after 12 months of employment)
• Adoption & Surrogacy Assistance
• Employee Assistance & Wellness Programs

• Short-Term & Long-Term Disability
• TDS Service Discounts
• Education Assistance
• Paid Volunteer Time

• Receives maps and staking sheets for the full construction project and ensures project is built, with limited guidance from supervisors.
• Communicates updates to the project team as required.
• Manages daily and weekly project work based on deadlines, material and equipment availability, weather, and other factors.
• Coordinates with supervisor to ensure continual supply of work and availability of materials.
• Drafts and submits redlines upon completion of project.
• Ensures locates are performed on time and prior to team and equipment arriving at the worksite.
• Regularly engages municipalities, utility companies, suppliers, contractors, and property owners in order to smoothly coordinate project tasks and avoid disputes.
• Reads construction plans and municipality permits, and determines approach for completing work.
• Maintains all project documentation and records costs of project materials and material transfers.
• Ensures DOT inspections are performed on equipment.
• Works with project managers to ensure projects remain on schedule and within budget.
• Performs general construction labor in various weather conditions while utilizing safety fundamentals.
  • Advanced operation of trenchers, backhoes, end loaders, plows, and other excavating equipment to construct and maintain outside plant cable facilities.
  • Advanced operation of all test equipment associated with outside plant facilities and construction duties.
  • Installs, troubleshoots, tests, splices, repairs, and maintains fiber optic facilities.
  • Identifies location of defective cable using various test equipment and repairs buried, aerial, underground, and/or customer cable.
  • Locates cable and fiber in response to customer requests and/or construction needs.
  • Performs cable fault acceptance tests on newly constructed facilities.
• Actively trains, monitors, and coaches team members while sharing construction knowledge and experience. Performs quality control inspections and makes training recommendations. Ensures safety protocols are enforced.
• Services, cleans, maintains, and repairs equipment.
• Completes all related paperwork in a timely manner.
• Provides assistance to field services technicians, as needed.

• 2+ years of construction equipment operation utilizing various underground and aerial construction equipment such as directional drills, trencher/plow/rock saw, backhoe, or bucket trucks -OR- current military service, or prior military service with honorable discharge.
• 1+ years of experience leading construction projects as a crew foreperson or project manager.
• Must follow the TDS attendance guidelines in order to meet TDS's business needs including but not limited to our obligations to our customers and to our customers' needs.
• Must have and maintain a valid driver's license and remain eligible for DOT requirements.

• Must have the ability to obtain a Class A CDL. A current CDL is preferred at hire, but TDS will train and certify eligible associates through its in-house CDL certification program after hire.
• Physical requirements may vary based on company needs: Ability to climb poles, ladders, towers, and other structures as needed. Ability to kneel, dig, lift, and pull.
• Upon hire, must successfully pass all components of the Safety Training course curriculum.
• Upon hire, must successfully complete customer-specific requirements, which may include a background check administered by the customer.
• Preferred 2+ years' experience in the construction of fiber optic cable outside plant networks -OR- 2+ years installation of any underground or overhead utilities will be considered.
• Understanding of telecommunication products and services.
• Proven organizational skills and ability to multi-task.
• May require occasional travel.
• Must be willing to work overtime as needed. May be required to work various/swing shifts as business needs dictate.
• Must be able to operate vehicles with manual transmissions.

• Medical Coverage
• Dental Coverage
• Vision Coverage
• Life Insurance
• 401(k) Plan
• Generous Vacation & Paid Sick Leave
• Seven Paid National Holidays & One Floating Holiday
• Paid Parental Leave (6 weeks after 12 months of employment)
• Adoption & Surrogacy Assistance
• Employee Assistance & Wellness Programs

• Short-Term & Long-Term Disability
• TDS Service Discounts
• Education Assistance
• Paid Volunteer Time

Job Title: Pre-Construction Manager / Estimator (Bilingual – English/Spanish)

Federal Energy & Infrastructure Projects

Job Type: Contract (W2)

Start Date: March 30, 2026

End Date: November 28, 2026 (with potential for extension)

Job Location: Knoxville, TN (onsite role that also includes up to 25% travel)

Work Schedule/Hours: Monday-Friday, 8 hours per day (standard business hours)

Compensation: $54.00 to $60.00 per hour

Overview: Our construction services client's federal construction team is seeking a (bilingual) Pre-Construction Manager / Estimator to support large-scale federal energy and infrastructure projects. This role will lead pre-construction planning, MEP estimating, bid development, and subcontractor procurement for complex Army construction work, including a major project in Puerto Rico. They're ideally looking for a seasoned estimator with deep mechanical, electrical, and plumbing (MEP) experience who can support projects from development through bidding, evaluation, and award.

What You’ll Do:

• Develop Independent Cost Estimates (ICE) and ROM estimates across all design phases

• Perform detailed quantity take-offs and MEP estimating

• Prepare pricing packages for RFP/RFQ submissions

• Source, qualify, and evaluate subcontractor bids

• Support bid leveling, negotiations, and award recommendations

• Coordinate with engineering, development, utilities, and construction teams

• Facilitate pre-bid walks and support proposal compliance

What You Bring:

• High school diploma (or GED) required; bachelor's degree (preferred)

• Fluent Spanish and English

• 8+ years of industrial/commercial pre-construction and estimating experience

• Strong MEP estimating background (mechanical, electrical, controls)

• Proficiency with RSMeans and industry estimating tools

• Ability to manage multiple priorities in a fast-paced federal environment

• Experience supporting federal or public-sector construction projects (preferred)

Job Title: Electrical Construction Manager (Semiconductor/Commissioning)

Location: Boise, ID (On-Site)

Duration: 1-2 Years

Pay Rate: $70/hr - $90/hr

**Visa Sponsorship is not available for this position***

Summary

Verigent is looking for an Electrical Construction Manager to oversee the planning, coordination, and execution of electrical systems on a high-tech construction project. This role is critical to ensuring the successful delivery of high-performance, mission-critical infrastructure that meets the highest standards of quality, safety, and efficiency. This individual will be an integral member of the on-site Electrical Team, managing all aspects of electrical construction from pre-construction through commissioning. This individual will collaborate with cross-functional teams, manage subcontractors and vendors, and help deliver mission-critical infrastructure on time, within budget, and to the highest quality and safety standards. This position will be fully at the project site near Boise, Idaho.

Essential Responsibilities

• Supervise and mentor on-site electrical teams, subcontractors, and vendors.
• Serve as the electrical systems technical advisor at onsite field construction office.
• Provide electrical systems technical support in the field, including layout, verification, and sequencing of installations.
• Lead planning, scheduling, and monitoring electrical construction activities.
• Lead or support meetings involving area managers, design team members, multiple subcontractors, and client representatives.
• Facilitate daily coordination meetings and resolve field issues promptly.
• Attend and contribute to pre-installation meetings; assist in documentation of as-built conditions.
• Interface between area managers and multiple subcontractors to assist with resolution of field coordination items.
• Coordination with engineering consultants, architects, vendors, and client representatives.
• Review, interpret, and coordinate electrical design drawings, construction documents, technical manuals, and quantifying materials required for construction from the documents.
• Review and process shop drawings, product data, and technical submittal information; cross-coordinate between submittals to ensure the compatibility and constructability.
• Generate, receive, and distribute Requests for Information (RFI).
• Receive and distribute change documents, bulletins and field directives issued by other team members.
• Support BIM coordination and participate in clash detection and resolution processes.
• Coordination installation and inspection of various electrical system components such as switchgear, UPS systems, generators, PDUs, bus ducts and low-voltage systems.
• Ensure compliance with local codes, standards (e.g., NEC, IEEE), and client requirements.
• Lead QA/QC efforts for the electrical installations, including participation pre-functional testing and systems start up.
• Maintain documentation for inspections, testing and commissioning.
• Assist in the commissioning and turnover of systems.
• Collaborate with Mechanical, Plumbing, CSA, and other Electrical Construction Managers to ensure integration of civil, architectural, structural, and MEP systems.
• Enforce strict adherence to safety protocols and procedures.
• Conduct regular site inspections and audits to ensure a safe working environment.
• Provide regular updates to project stakeholders on progress, risks, and mitigation strategies.
• Maintain accurate records of project changes, RFIs, submittals and as-built documentation.

Required Qualifications

• Minimum 5 years of Electrical Construction Management experience in commercial building construction required, with at least 3 years in hyperscale or mission-critical data center environments.
• Proven experience managing large-scale electrical installations, preferably in hyper-scaled data centers.
• Strong understanding of electrical infrastructure and systems including high voltage, medium voltage, and low voltage distribution, UPS, generators, grounding and BMS integration.
• Knowledge of Uptime Institute or other data center standards.
• Deep understanding of construction means and methods, trade sequencing, and commissioning processes and integrated systems testing.
• OSHA 30 certification or equivalent safety training preferred.
• High School diploma or GED required.
• Bachelor of science in civil engineering, mechanical engineering, electrical engineering, structural engineering, construction management or equivalent degree and/or equivalent craft level work experience.
• PMP or similar project management certification preferred.

Position Related Skills

• Proficient in Windows and Microsoft Office 365 (Excel, Word, Outlook, Power Point and Teams), and have a strong understanding of working within a computer network.
• Experience with project management software such as Prolog, Procore, E-Builder, Bluebeam, Microsoft Project, and Primavera Project Planner (P6).
• Experience with design software such as AutoCAD, Revit and Navisworks.
• Training in design and construction document reading, design specifications, survey theory and techniques.
• Experience in organizing technical data in a neat and accurate method. Familiar with Construction Specifications Institutes (CSI) MasterFormat.
• Strong understanding of construction means and methods, sequencing, and field practices.
• Capable of organizing and analyzing technical data effectively and accurately.
• Ability to work well and maintain a cooperative attitude in a fast-paced environment and manage multiple priorities.
• Excellent time-management skills and ability to multi-task and prioritize work while frequently interrupted by phone calls and questions on work in progress.
• Excellent written and oral communication skills with an ability to develop strong interpersonal relationships.
• Ability to work closely with variety of trade and craft people in a field work situation. Patience and professionalism are essential.
• Must be a strong team player with the ability to collaborate with various personnel within and across departments and at all levels of leadership.
• Work schedule must be flexible to allow extended hours or off shift work to accommodate changing construction schedule and sequences.

Physical and Mental Requirements

• Standing/Walking/Sitting: Workday is a combination of being stationary and moving about the work location.
• Must be able to work outdoors in varying weather conditions and on active construction sites.
• Must be able to climb stairs, to ascend and descend ladders, scaffold, inspect confined or underground spaces.
• Hands/Arms: Constantly operates a computer and other office productivity machinery. Frequently operates machinery and will use hand/fingers and legs to operate, activate, use, prepare, inspect, place, detect, and position materials.
• Sight: Specific vision abilities required include close vision, depth perception and the ability to adjust focus in an outdoor environment. Must be able to safely operate a vehicle with a valid driver’s license. The work is required to have close visual acuity to perform an activity such as preparing and analyzing data and figures, transcribing, viewing a computer terminal, reading print and digital documents.
• Hearing: Must be able to work in proximity to loud equipment more than 50% of the time. Must be able to wear hearing protection, as necessary. Often required to communicate with customers and co-workers in an office setting and on the job site.
• Speech: Ability to communicate laws, ordinances, plans, regulations, protocols, directives, and standard operating procedures related to project scope in English.
• Lift/Carry: Must have the ability to lift or manipulate fifty pounds to a height of three feet and carry or push it 50-100 feet.
• Bending/Twisting: Frequent.
• Kneeling/Crouching/Crawling: Must be able to regularly position self in a kneeling, crouching or crawling position for purpose of examining project work.
• Must be able to physically access all areas and levels of construction site for work progress review.
• Work schedule must be flexible to allow for extended hours or off shift work to accommodate changing construction schedule and sequences.
• Must use independent judgment, organizational and critical thinking skills to determine best method to accomplish desired results.

• 
  
• RFP development and budgeting
  
• Pre-bid oversight and coordination
  
• Managing all design phases and documents
  
• Conduct project meetings, publish, and distribute minutes, develop milestones, and maintain monthly reports.
  
• Manage day-to-day office and field operations.
  
• Review the plans and specifications for constructability and construction schedules. Advise the project team of any issues or deficiencies.
  
• Prepare, manage, and update the detailed project schedule with sequence and activity duration including procurement items.
  
• Customer engagement for sales and fulfillment of requirements
  
• Coordination and supervision of design-build contractors
  
• Coordination with internal stakeholders and subject matter experts
  
• Oversight of physical construction activities
  
• Participation in commissioning
  
• The management of close out and hand-off of physical data center and project documents to customer
  
• Collaborate with the design team, operators, and clients.
  
• Submit monthly project financial reporting, including forecasting, cash-flow, etc.
  
• Review monthly contractor billing and perform job walks to substantiate progress.
  
• Keeps all relative parties informed of progress throughout the life of the project.
  
• Develop, manage, maintain, and assist with contract negotiation of new and existing vendors.
  
• Oversee RFI and Submittal Review Process.
  
• Manage the Change Order Process with Owner and Subcontractors.
  
• Manage input and delivery of work products from internal team members to ensure that new data center spaces comply with the project requirements, customer requirements, all engineering standards, applicable codes, and specifications.
  
• Understand project budget/estimate and budget set-up.
  
• Develop and understand trade contractor and supplier contract scopes, with a constant focus on procurement and lead-time of materials to maintain schedule.
  
• Develop, document, and drive lessons learned, process improvements, cost, and schedule savings initiatives throughout the project lifecycle.
  
• Work closely with the proposal team to coordinate design criteria with budgetary issues and ongoing maintenance and operation of existing facilities.
  
• Awareness of the importance of mission-critical facility operation
  
• Safety standards knowledge and enforcement. (OSHA 30 Hour preferred)
  
• *Schedule shifts may incl nights/weekends as per bell curve requirements
  
• Additional duties may be assigned as project needs adjust at Management's discretion.
  
• Must be able to do 30% travel
  
• Must be a US Citizen
  

• 
  
• Bachelor of Science in Construction Management, or a similar field, or equivalent experience
  
• Construction/Engineering/Architectural degree a plus
  
• 5 years of experience in managing construction projects required
  
• Datacenter experience is preferred
  
• Experience in CSA (civil, structural, architectural) and MEP (mechanical, electrical, plumbing) construction management is a requirement.
  

The Broward County Board of County Commissioners is seeking qualified candidates for Construction Project Manager-Crane Section at Port Everglades.



The Construction Project Manager in the Operations Division - Crane Section is responsible for performing advanced professional and administrative work in the design and management of crane improvement projects for the Port Everglades Department.

THIS JOB ANNOUNCEMENT WILL REMAIN OPEN UNTIL SUFFICIENT NUMBER OF APPLICATIONS ARE RECEIVED AND MAY CLOSE AT ANYTIME.

General Description

Performs advanced professional and administrative work in the design and management of construction projects for the County.

Works independently, under limited supervision, reporting major activities through periodic meetings.

Requires an associate degree from an accredited college or university with major coursework in architecture, civil engineering, construction management or closely related field.

Requires Eight (8) years of professional engineering and/or construction management experience relevant to the area of assignment or closely related experience.

Possess and maintain a valid Florida Class E Driver's License based on area of assignment.

Ability to secure and maintain a Transportation Worker Identification card (TWIC) within 60 days of employment and for the duration of employment.

• Bachelor's or master's Degree from an accredited college or university with major coursework in Architecture, Civil Engineering, Construction Management, or closely related field
• Project Management Professional (PMP) certification
• LEED certification
• Licensed Engineer in the State of Florida, or Licensed General or Building Contractor in the State of Florida
• 1+ years experience using AutoCAD
• 1+ years experience using Building Information Modeling (BIM)
• 5+ years of experience in governmental accounting and procurement processes
• 3+ years of experience gantry crane maintenance

Duties and Responsibilities

The functions listed below are those that represent the majority of the time spent working in this class. Management may assign additional functions related to the type of work of the job as necessary.

Develop and prepare engineering plans and designs for various crane improvement projects; estimate quantities and costs of such projects.

Assists consultants in the development of construction projects; issues work orders to consultants, surveyors and testing labs; reviews consultant's plans and specifications at various stages of development for conformance to design standards, completeness and accuracy; monitors consultant's cost estimates and verifies consultant's invoices and recommends payment.

Coordinates bid advertisements; schedules and assists in conducting pre-bid conferences; assists in evaluating bids and making recommendations for award of contract.

Schedules and assists in conducting pre-bid construction meetings with consultants, contractors and subcontractors; issues Notice to Proceed to contractors; reviews field inspection reports.

Assists in the preparation of schedules and monitors construction progress; assists in the preparation of change orders; maintains records of consultant's payments.

Assists in the inspection of projects for substantial completion and prepares punch list of any deficiencies; arranges for correction of defects by contractor during warranty period and conducts inspection at end of warranty period to ensure correction of defects.

Prepares required paperwork for capitalizing and closing the project; performs special investigations, sites analyses and feasibility studies as required and submits technical and management reports.

Meets with consultants, contractors, utility organizations, city, state, federal agencies, civic associations, business and community leaders, property owners and attorneys; assists with the preparation of the budget for capital expenditures.

Makes recommendations regarding hiring, discipline and promotions of subordinates; authorizes leave; evaluates employee performance.

Performs related work as assigned.

• Financial Acumen:Interprets and applies key financial indicators to make better business decisions. Determines and estimates the main direct and indirect costs; makes generally appropriate decisions regarding expenditures. Studies financial and quantitative information; uses data to improve performance.
• Manages Complexity:Makes sense of complex, high quantity, and sometimes contradictory information to effectively solve problems. Consistently looks at complex issues from many angles; obtains a rich and deep understanding; swiftly cuts to the core issue; skillfully separates root causes from symptoms.
• Decision Quality:Makes good and timely decisions that keep the organization moving forward. Knows when to act independently and when to escalate issues. Integrates various inputs, decision criteria, and trade-offs to make effective decisions. Typically makes good independent decisions.
• Balances Stakeholders:Anticipates and balances the needs of multiple stakeholders. Ensures that own efforts meet the needs and requirements of internal and external stakeholders. Works to identify all relevant issues and satisfy the interests of multiple stakeholders during the decision-making process.
• Plans and Aligns:Plans and prioritizes work to meet commitments aligned with organizational goals. Stays focused on plans and improvises in response to changes, including risks and contingencies. Aligns own team's work with other workgroups'. Looks ahead to determine and obtain needed resources to complete plans.
• Ensures Accountability:Holds self and others accountable to meet commitments. Accepts responsibility for own work, both successes and failures. Handles fair share and does not make excuses for problems. Usually meets commitments to others.
• Drives Results:Consistently achieves results, even under tough circumstances. Holds self to high standards of performance; sets some challenging goals; wants to achieve meaningful results; pursues initiatives/efforts to successful completion and closure. Focuses on key goals, even during setbacks and obstacles.
• Communicates Effectively:Develops and delivers multi-mode communications that convey a clear understanding of the unique needs of different audiences. Tailors communication content and style to the needs of others. Pays attention to others' input and perspectives, asks questions, and summarizes to confirm understanding.
• Situational Adaptability:Adapts approach and demeanor in real time to match the shifting demands of different situations. Sees even subtle cues to adapt; deploys a wide range of behaviors to stay effective. Exemplifies flexibility and resourcefulness; responds deftly to a variety of challenges and situations.

Physical Demands

Physical demands refer to the requirements for physical exertion and coordination of limb and body movement.

Performs light work that involves walking or standing most of the time and involves exerting up to 20 pounds of force on a regular and recurring basis, or skill, adeptness and speed in the use of fingers, hands or limbs on repetitive operation of electronic office equipment or tools within moderate tolerances or limits of accuracy.

Unavoidable hazards refer to the job conditions that may lead to injury or health hazards even though precautions have been taken.

Involves routine and frequent exposure to traffic; moving machinery.

County Core Values

All Broward County employees strive to demonstrate the County's four core behavioral competencies.

• Collaborates: Building partnerships and working collaboratively with others to meet shared objectives.
• Customer focus: Building strong customer relationships and delivering customer-centric solutions.
• Instills trust: Gaining the confidence and trust of others through honesty, integrity, and authenticity.
• Values differences: Recognizing the value that different perspectives and cultures bring to an organization.

Copyright 2025 Korn Ferry. ALL RIGHTS RESERVED

Broward County is an Equal Opportunity Employer committed to inclusion. Broward County is committed to providing equal opportunity and reasonable accommodations to qualified persons with disabilities. We support the hiring of people with disabilities; therefore, if you require assistance due to a disability, please contact the Professional Standards Section in advance at or email to make an accommodation request.

Note: During emergency conditions, all County employees are automatically considered emergency service workers. County employees are subject to being called to work in the event of a disaster, such as a hurricane, or other emergency situation and are expected to perform emergency service duties, as assigned.

All Broward County employees must serve the public and fellow employees with honesty and integrity in full accord with the letter and spirit of Broward County's Employee Code of Ethics, gift, and conflict of interest policies.

All Broward County employees must establish and maintain effective working relationships with the general public, co-workers, elected and appointed officials and members of diverse cultural and linguistic backgrounds, regardless of race, color, religion, sex, national origin, age, disability, marital status, political affiliation, familial status, sexual orientation, pregnancy, or gender identity and expression.

Overview
Georgia Tech prides itself on its technological resources, collaborations, high-quality student body, and its commitment to building an outstanding and diverse community of learning, discovery, and creation. We strongly encourage applicants whose values align with our institutional values, as outlined in our Strategic Plan. These values include academic excellence, diversity of thought and experience, inquiry and innovation, collaboration and community, and ethical behavior and stewardship. Georgia Tech has policies to promote a healthy work-life balance and is aware that attracting faculty may require meeting the needs of two careers.

About Georgia Tech
Georgia Tech is a top-ranked public research university situated in the heart of Atlanta, a diverse and vibrant city with numerous economic and cultural strengths. The Institute serves more than 45,000 students through top-ranked undergraduate, graduate, and executive programs in engineering, computing, science, business, design, and liberal arts. Georgia Tech's faculty attracted more than $1.4 billion in research awards this past year in fields ranging from biomedical technology to artificial intelligence, energy, sustainability, semiconductors, neuroscience, and national security. Georgia Tech ranks among the nation's top 20 universities for research and development spending and No. 1 among institutions without a medical school.

Georgia Tech's Mission and Values
Georgia Tech's mission is to develop leaders who advance technology and improve the human condition. The Institute has nine key values that are foundational to everything we do:
1. Students are our top priority.
2. We strive for excellence.
3. We thrive on diversity.
4. We celebrate collaboration.
5. We champion innovation.
6. We safeguard freedom of inquiry and expression.
7. We nurture the wellbeing of our community.
8. We act ethically.
9. We are responsible stewards.

Over the next decade, Georgia Tech will become an example of inclusive innovation, a leading technological research university of unmatched scale, relentlessly committed to serving the public good; breaking new ground in addressing the biggest local, national, and global challenges and opportunities of our time; making technology broadly accessible; and developing exceptional, principled leaders from all backgrounds ready to produce novel ideas and create solutions with real human impact.

Department Information
The Campus Services capital projects team enhances the Institute's physical environment by managing design and construction for renovation, infrastructure, access control, and new construction projects that support the department and serve our students.

Direct the contract management and project team activities for one or more large assigned capital building projects from inception to final completion. Responsible for setting employee goals, assessing performance, providing feedback, and making pay recommendations. This position will interact on a consistent basis with: Design & Construction management and staff, Facilities management, contractors, architects. This position typically will advise and counsel: Design & Construction management and staff, Facilities management, contractors, architects. This position may supervise assigned project managers.

Job Duty 1
Oversee the development and negotiations leading to building projects.

Job Duty 2
Prepare RFQ/RFP leading to A& E contracts, construction contracts, design-build contracts and other consulting and construction agreements.

Job Duty 3
Review proposals and recommend contract awards.

Job Duty 4
Manage the design and construction phases of assigned projects.

Job Duty 5
Administer project budgets and schedules.

Job Duty 6
Prepares and presents construction progress reports.

Job Duty 7
Plan, supervise and evaluate performance of assigned staff.

Job Duty 8
Perform other duties as assigned Required Qualifications

Educational Requirements
Bachelor's Degree in Construction Management or related field or equivalent combination of education and experience

Other Required Qualifications
Requires 12 hour work days when involved in supervision of staff working on special projects

Required Experience
Five to six years of job related experience

Additional Preferred Qualifications
Registered Architect, Professional Engineer or Project Management Professional certification , LEED AP certification

SKILLS
This job requires working knowledge the principles and processes associated with construction engineering. Ability in negotiation, contract administration, project management, communications, budgeting, and use of standard and specialized computer applications is required.

The University System of Georgia is comprised of our 25 institutions of higher education and learning as well as the System Office. Our USG Statement of Core Values are Integrity, Excellence, Accountability, and Respect. These values serve as the foundation for all that we do as an organization, and each USG community member is responsible for demonstrating and upholding these standards. More details on the USG Statement of Core Values and Code of Conduct are available in USG Board Policy 8.2.18.1.2 and can be found on-line at policymanual/section8/C224/#p8.2.18_personnel_conduct.

Additionally, USG supports Freedom of Expression as stated in Board Policy 6.5 Freedom of Expression and Academic Freedom found on-line at policymanual/section6/C2653.

The Georgia Institute of Technology (Georgia Tech) is an Equal Employment Opportunity Employer. The Institute is committed to maintaining a fair and respectful environment for all. To that end, and in accordance with federal and state law, Board of Regents policy, and Institute policy, Georgia Tech provides equal opportunity to all faculty, staff, students, and all other members of the Georgia Tech community, including applicants for admission and/or employment, contractors, volunteers, and participants in institutional programs, activities, or services. Georgia Tech complies with all applicable laws and regulations governing equal opportunity in the workplace and in educational activities.

Equal opportunity and decisions based on merit are fundamental values of the University System of Georgia ("USG") and Georgia Tech. Georgia Tech prohibits discrimination, including discriminatory harassment, on the basis of an individual's race, ethnicity, ancestry, color, religion, sex (including pregnancy), national origin, age, disability, genetics, or veteran status in its programs, activities, employment, and admissions. Further, Georgia Tech prohibits citizenship status, immigration status, and national origin discrimination in hiring, firing, and recruitment, except where such restrictions are required in order to comply with law, regulation, executive order, or Attorney General directive, or where they are required by Federal, State, or local government contract.

Salary range: $103,345.00- $117,145.00

Location: Atlanta, GA

Job grade: S8

This is a supervisory position.
This position does not have any financial responsibilities.
This position will be required to drive.
This role is considered a position of trust.
This position does not require a purchasing card (P-Card).
This position will not travel
This position does not require security clearance.

A successful candidate must be able to pass a background check. Please visit employment/pre-employment-screening

Construction Manager (Mechanical)

Location: Biloxi, Mississippi

Employment Type: Full-Time, Onsite

FLSA Classification: Exempt

Salary Range: $110,000– $125,000 annually (commensurate with experience)

Position Summary

Seeking motivated Project Managers/Construction Managers (PM/CM) with a degree in Mechanical Engineering to join our team at a VA Hospital in Biloxi, Mississippi. Candidates will act as Design and Construction Managers reporting to a Program Manager as well as collaborate and assist VA client staff to provide data, generate reports, as a representative for the client on major healthcare construction projects.

Who Will Succeed in This Role

This role is best suited for professionals who:

• Have supported complex construction projects within healthcare, government, or institutional environments
• Are comfortable analyzing financial, schedule, and compliance data to support program-level decisions
• Can operate independently while collaborating effectively with program leadership, clients, and contractors
• Leadership: Must possess the skillset and competence to work with and manage personnel of diverse skillsets.

Key Responsibilities

The Construction Manager will be a part of a team of professionals and act as the Owner's Representative role on these programs from design through construction and closeout. The Construction Manager will be required to learn and integrate our company’s best practices related to project delivery, budget, schedule, quality and operations in the healthcare environment. The Construction Manager will act as an advisor/liaison with the client (user groups, design team, contractors, and facility engineering representatives). The Construction Management services will be used to support traditional Design-Bid-Build and Design/Build contracts. A summary of the major tasks is below.

• Analyze and monitor project financial data, budget performance, and cost trends
• Review construction schedules and support progress and performance evaluations
• Participate in progress meetings and support issue identification and resolution
• Review testing, inspection, and quality assurance documentation for compliance
• Support claims administration, change management, and contract modifications
• Review contractor work documentation and reported progress for conformance with construction documents and approved schedules
• Prepare analytical reports, correspondence, and program status documentation
• Maintain tracking tools and reporting systems supporting program oversight
• Advise program leadership on construction administration best practices and compliance considerations

Education & Experience

Education

• Bachelor’s degree of Mechanical Engineering from an accredited institution is preferred; equivalent combinations of education and relevant experience will be considered.

Experience

• Minimum of six (6) years of progressively responsible experience in construction administration, construction management, or a closely related field
• Experience supporting regulated environments (federal, healthcare, or institutional) is highly desirable
• Candidates may be asked to provide examples or documentation of completed projects demonstrating relevant experience
• Requirements of local state and federal jurisdiction in relation to the Project.
• Construction Contract Documents including Front End and Technical Specifications and drawings to readily understand and assess requirements.
• Working knowledge of engineering services, building codes budgeting and scheduling to lead the project’s success.

Additional Requirements

• Familiarity with construction practices, quality assurance, scheduling, cost management, and change management
• Demonstrated ability to exercise independent judgment in administrative, financial, and compliance matters
• Proficiency with Microsoft Office Suite and Adobe Acrobat
• Strong written, verbal, and organizational communication skills

Preferred Qualifications

• Leadership: Must possess the ability to collaborate and integrate with other professionals
• Building construction experience
• Experience with Healthcare and Federal projects.
• CCM, PMP certifications

Work Environment & Physical Requirements

• Full-time onsite work at an active construction site and office environment
• Ability to sit, stand, walk, and use standard office equipment
• Reasonable accommodations will be provided to qualified individuals with disabilities in accordance with applicable laws

Federal & VA Program Requirements

• Employment may be contingent upon successful completion of background checks and compliance with federal and VA suitability requirements
• Must adhere to all site safety, security, and confidentiality policies

Benefits (Full-Time Employees)

• Medical, Dental, Vision Insurance (99% of individual base plan paid by company; 50% for dependents)
• 401(k) with up to 4% company match
• Paid Time Off and Paid Holidays
• Annual bonus eligibility based on individual and company performance

About SIRIS

SIRIS, LLC is a CVE-verified, Service-Disabled Veteran-Owned Small Business (SDVOSB) specializing in construction management, project management, and commissioning services for federal, healthcare, and institutional clients nationwide.

We are a trusted partner on complex projects ranging from targeted renovations to large-scale developments, bringing technical expertise, accountability, and collaboration to every engagement. Our mission-driven approach supports healthcare, cultural, and government facilities where quality, reliability, and compliance are critical.

Equal Opportunity Employer

SIRIS, LLC is an Equal Opportunity Employer and federal contractor. All qualified applicants will receive consideration for employment without regard to race, color, religion, sex, sexual orientation, gender identity, national origin, age, disability, protected veteran status, or any other status protected by applicable federal, state, or local law.

Title: Construction Project Manager (Self-Performing)

Location: Murrieta, CA (Inland Empire)

Salary Range: $163K to $185K DOE

This position is responsible for the administration and execution of assigned projects in a safe, profitable, and timely manner. Assigned projects of larger contract amounts and complexity, establishes and maintains a professional working relationship with owners, architects, engineers, subcontractors, and suppliers. Additionally, this position may be responsible to participate in business development, estimating, bidding, and contract negotiation phases of the projects assigned.

Essential duties and other responsibilities include, but are not limited to, the following:

• Manages the project team to include project procurement, administration, and daily team operations.
• Ensures assigned projects are completed on time, under budget and at a profit on a timely and effective manner.
• Determines resources needed and defines responsibilities assigned to specific team members.
• Provides input and supervises all pre-construction services such as purchase orders, subcontracts, schedules, job cost set-up, and project pre-planning.
• Serves as a liaison to initiate contact between clients, estimators, on-site superintendents, or others to facilitate construction activities and maintain a high degree of customer satisfaction.
• Participates in project coordination meetings.
• Establishes project objectives, policies, and procedures within contract guidelines.
• Ensures all project documentation is completed in a timely manner and maintained in the appropriate master project files.
• Dedicated to achieving a "Zero Accident Culture" by developing and implementing site safety protocols and adherence to OSHA safety standards.
• Works with project Superintendent to obtain resources required to properly staff construction project.
• Reviews change orders for accuracy.
• Adheres to insurance, labor relations, Equal Employment Opportunity (EEO), risk management, and quality control programs and protocols.
• Ensures project site and company assets are secure.
• Always maintains a safe and respectful working environment.
• Directs and ensures timely completion of project close-out activities.
• Supervises small projects and provides supervisory assistance with large projects.
• Carries out supervisory responsibilities in accordance with the organization's policies and applicable laws.
• Trains employees, plans, assigns, and directs work, appraises performance, encourages, and disciplines employees, addresses complaints, and resolves problems.

To perform this job successfully, an individual must be able to perform each essential duty satisfactorily. The requirements listed below are representative of the knowledge, skill, and/or ability required. Reasonable accommodations may be made to enable individuals with disabilities to perform the essential functions.

Required Education and Experience:

Bachelor of Science degree in Construction Management, Civil Engineering, related field or equivalent experience.

This position is responsible for the administration and execution of assigned projects in a safe, profitable, and timely manner. Assigned projects of larger contract amounts and complexity, establishes and maintains a professional working relationship with owners, architects, engineers, subcontractors, and suppliers. Additionally, this position may be responsible to participate in business development, estimating, bidding, and contract negotiation phases of the projects assigned.

Required Education and Experience

• Bachelor of Science degree in Construction Management, Civil Engineering, related field or equivalent experience.
• 7+ years of project engineer experience in the field of water and wastewater treatment, water conveyance, sewers and sewer rehabilitation.
• Experience managing vendor relationships and understanding standard practices in the design and construction industry, including knowledge of the design build process and associated documents and contracts.
• Knowledge of construction cost, scheduling, estimating, and engineering principals and techniques, as well as accounting principles.
• Knowledge of various construction methods and materials, their characteristics, installation procedures and tolerance.
• Strong computer skills and familiarization with software programs for job costing, scheduling and estimating.
• Excellent verbal and written communication skills.

Certificates, Licenses, Registrations

• A valid California Driver's License
• Licensed Professional Engineer (preferred)

To perform this job successfully, an individual should demonstrate the following competencies:

• Effective Communication
• Results Oriented
• Collaboration
• Presentation Skills
• Initiative
• Thoroughness
• Business Acumen
• Conflict Management
• Personal Integrity

Physical Demands

• The physical demands described here are representative of those that must be met by an employee to successfully perform the essential functions of this job.
• Experience managing vendor relationships and understanding standard practices in the design and construction industry, including knowledge of the design build process and associated documents and contracts.
• Knowledge of construction cost, scheduling, estimating, and engineering principals and techniques, as well as accounting principles.
• Knowledge of various construction methods and materials, their characteristics, installation procedures and tolerance.
• Strong computer skills and familiarization with software programs for job costing, scheduling and estimating.
• Excellent verbal and written communication skills.

Construction Project Scheduler

'We're all Americaribe'. It means that we share the same culture, expertise & refers to the efforts we take every day to make ourselves operate more tightly and agilely. Our pride, achievements, and experiences have all tied to the minds of teamwork, innovation, and novelty. Talented newcomers with creative and technical skill sets like these, along with an energy and enthusiasm that effectively contribute to team morale, are always needed as Americaribe continues to grow. Beyond the high-level benefits and competitive salary is a plethora of opportunity to accentuate your career path, allowing growth from advanced trainings and experience, provided by Americaribe, to build leadership, versatility, & consistency. Americaribe LLC is known for applying its capacity for technical and commercial innovation, cutting-edge engineering skills and expertise in development to offices, hotels, airports, hospitals, schools, housing, exhibition centers, leisure facilities, etc. Americaribe is the subsidiary of Bouygues Bâtiment International, operating in over twenty countries, also known for combining its networks alongside major contracts with highly added value.

POSITION SUMMARY

The Project Scheduler is responsible for developing, maintaining, and monitoring project schedules to ensure construction projects are delivered on time and within budget. This role collaborates closely with project managers, preconstruction managers, estimators, superintendents, subcontractors, and clients to coordinate timelines, monitor progress, identify risks, and recommend corrective actions when necessary.

ESSENTIAL DUTIES AND RESPONSIBILITIES

Schedule Development & Planning

• Develop detailed baseline schedules using tools such as Primavera P6, Microsoft Project, or similar scheduling software, covering all project phases from RFP/Project Launch through Substantial Completion and Final Turnover.
• Create Work Breakdown Structures (WBS) and define project activities, durations, and sequencing.
• Establish logic-driven critical path (CPM) and identify schedule constraints.
• Resource load schedules with quantities, labor, and cost data when required.
• Prepare schedule narratives documenting assumptions and methodologies.
• Collaborate with project managers, preconstruction managers, field teams and estimators during both preconstruction and construction phases.

Schedule Monitoring & Control

• Conduct site visits to assess and document construction progress.
• Update schedules regularly to reflect actual progress.
• Perform critical path analysis and identify variances.
• Develop recovery schedules when delays occur.
• Perform Time Impact Analyses (TIA) to assess the effects of change orders and scope modifications.

Means & Methods

• Define construction means and methods required to achieve schedule objectives.
• Develop site logistics and Maintenance of Traffic (MOT) plans in 2D or 3D formats.

Reporting & Communication

• Prepare and distribute schedule reports, dashboards, executive summaries, and look-ahead schedules.
• Present schedule status updates to internal stakeholders and clients.
• Provide scheduling input for executive reports and owner meetings.
• Maintain documentation to support claims and delay analyses when required.

Risk Management

• Identify schedule-related risks and recommend mitigation strategies.
• Conduct what-if scenario analysis to evaluate alternative approaches.
• Support dispute resolution efforts through detailed time impact analysis.

Collaboration

• Coordinate with project management, engineering, procurement, and subcontractors to ensure schedule alignment.
• Support resource planning and labor forecasting efforts.
• Ensure alignment between field operations and master project schedules.
• Perform other duties as assigned.

QUALIFICATIONS

Education

• Bachelor’s degree in construction management, engineering, or related field (preferred).

Experience

• 3 to 7+ years of experience in construction scheduling or project controls preferably within the US, South Florida or the Caribbean.
• Experience on commercial, industrial, infrastructure, or residential projects.

Technical Skills

• Advanced proficiency in Primavera P6 and Microsoft Project.
• Strong understanding of construction sequencing means and methods.
• Solid knowledge of Critical Path Method (CPM) scheduling.
• Familiarity with cost control, earned value management (EVM) principles
• Ability to use construction resources data to validate productivity rates and activity durations.
• Proficient in Microsoft Office Suite (including Excel), Power BI, Bluebeam is a must.
• Working knowledge of (or willingness to learn) BIM, Revit, AutoCAD, Navisworks, cmBuilder and Synchro 4D.
• Ability to interpret contract documents, drawings, specifications, and scopes of work.
• Ability to perform quick quantity take-offs for scheduling purposes.

Soft Skills

• Strong analytical and problem-solving skills.
• Excellent written and verbal communication skills.
• High level of attention to detail and organizational skills.
• Ability to manage multiple projects simultaneously.
• Experience working with multidisciplinary and multicultural teams.
• Innovative mindset with curiosity toward emerging technologies.

PREFERRED CERTIFICATIONS (OPTIONAL)

• PMI Scheduling Professional (PMI-SP).
• Project Management Professional (PMP).
• Planning & Scheduling Professional (PSP) – AACE.

WORK ENVIRONMENT

• Primarily office-based with regular visits to active construction sites.
• Travel may be required depending on project location.
• Full-time position with occasional extended hours to meet project deadlines.

Americaribe LLC is an Equal Opportunity Employer

Project Manager – Sustainable & Passive House Construction

San Jose, CA

• Type: Full-Time
• Salary: $130-135,000 for a PM (5-10 years’ experience) and $140,000-$160,000 for a senior PM (10+ years’ experience)

Build a Better Life by Building a Better Way

We don’t just build homes—we build a better world. Our team specializes in crafting exceptional custom homes and certified Passive Houses that combine superior craftsmanship, advanced building science, and environmental responsibility. We are deeply committed to sustainability, social equity, and long-term positive impact for our clients, employees, and the planet.

Are you a seasoned construction professional with a passion for high-performance, sustainable homebuilding? We are a Bay Area leader in healthy, energy-efficient, net-zero, and Passive House construction, and we’re seeking an experienced Project Manager to lead the successful delivery of our custom residential projects.

As a Certified B Corp with over $60M in backlog and projects booked through 2028, we offer long-term stability, meaningful work, and the opportunity to help shape the future of sustainable.

THE ROLE:

• As a Project Manager, you will oversee the planning, coordination, and execution of high-performance residential projects from pre-construction through closeout. You’ll manage schedules, budgets, teams, and client relationships to ensure every project reflects our uncompromising standards for quality, sustainability, and performance
• This is a critical, long-term role for a detail-oriented leader who thrives in a progressive, collaborative environment and is eager to grow with the company for years to come

KEY RESPONSIBILITIES:

Project Leadership & Oversight

• Manage multiple custom home and Passive House projects from design and permitting through completion
• Collaborate closely with pre-construction and company leadership from project inception
• Ensure seamless execution across all phases of construction

Budget & Schedule Management

• Develop, manage, and track detailed project budgets
• Monitor costs and ensure financial targets are met
• Create and maintain comprehensive project schedules, ensuring milestones and deadlines are achieved

Team & Stakeholder Coordination

• Lead and coordinate site superintendents, subcontractors, and trade partners
• Serve as the primary point of contact for clients, architects, engineers, and field teams
• Foster a collaborative, accountable, and solutions-oriented project culture

Quality, Compliance & Performance

• Ensure all work meets or exceeds company standards, building codes, and Passive House certification requirements
• Uphold best practices in high-performance building, including air sealing, insulation, and advanced HVAC systems
• Ensure compliance with local building codes, permitting, and environmental regulations

Documentation & Reporting

• Maintain accurate and organized project documentation, including contracts, change orders, schedules, and reports
• Produce daily, weekly, and milestone-based progress updates

Client & Vendor Relations

• Maintain strong client relationships through regular communication and transparent updates
• Ensure client vision, expectations, and sustainability goals are fully realized
• Procure materials, negotiate contracts, and manage supplier and vendor relationships

Problem Solving

• Anticipate project challenges and proactively develop solutions
• Adapt plans and resources to keep projects on track while maintaining quality and performance

QUALIFICATIONS:

Experience:

• At least 10+ years of residential construction experience
• Minimum 5 years in a project management role
• Proven experience managing custom home projects (required)
• Passive House or sustainable/high-performance construction experience (strongly preferred)

Technical & Professional Skills:

• Deep knowledge of residential construction methods, building codes, and permitting processes
• Strong understanding of high-performance building systems
• Expertise in budgeting, scheduling, and contract management
• Ability to manage multiple complex projects simultaneously

Leadership & Communication

• Proven ability to lead diverse teams and drive accountability
• Exceptional written and verbal communication skills
• Confident, respectful communicator with clients, consultants, and internal teams

Technology

• Proficiency with project management software (e.g., Procore, BuilderTrend)
• Strong working knowledge of Microsoft Office Suite

Education & Certifications (Preferred)

• Degree in Construction Management, Civil Engineering, or related field (preferred, not required)
• LEED AP, Passive House certification, and/or PMP a plus

Other Requirements

• Valid driver’s license and reliable transportation

Soft Skills & Cultural Fit

• Genuine passion for sustainability and energy-efficient building
• Strong attention to detail and ability to perform under pressure
• Proactive, solution-driven mindset
• Comfortable voicing ideas and opinions while collaborating across departments
• Embraces innovation, continuous improvement, and positive change

WHY JOIN US?

• Be part of a mission-driven company redefining residential construction
• Competitive salary and benefits package
• Long-term stability with a strong project pipeline through 2028
• Professional growth opportunities, including training in Passive House and advanced
• building science
• Supportive, collaborative, and forward-thinking company culture
• Work that makes a meaningful impact—for clients, communities, and the planet

We are an equal opportunity employer, and we are an organization that values diversity. We welcome applications from all qualified candidates, including minorities and persons with disabilities.

req26-00104

About PSI

Over the past 20 years, PSI has grown from a small carpentry business to a national construction company exceeding $400M in annual revenue. PSI focuses on Commercial, Retail, Grocery, Federal, and Design Build Construction across the United States. We offer our employees competitive base salaries, bonuses, benefits, 401k match programs, and paid time off (PTO).

Position Overview

Place Services, Inc. has an immediate need for a Preconstruction Manager in our Retail Division to lead our retail estimating efforts our of our HQ in Canton, GA.

The Preconstruction Manager is responsible for overseeing and executing the estimating strategy for retail construction projects while leading, mentoring, and developing the estimating team.

This role partners closely with executive leadership, operations, and business development to ensure competitive, accurate, and profitable bids.

Responsibilities

• Lead and manage all estimating activities for the Retail Division, ensuring consistency, accuracy, and competitiveness across all bids
• Develop and execute estimating strategies aligned with company goals, market conditions, and client expectations
• Oversee the solicitation of subcontractor and supplier pricing and maintain strong, long-term trade partner relationships
• Review and approve quantity takeoffs, pricing, assumptions, and final bid proposals prior to submission
• Prepare and/or oversee conceptual estimates and budgets based on limited or schematic-level information
• Review general conditions, schedules, scopes of work, logistics plans, phasing plans, and other project exhibits
• Analyze subcontractor bids, scope coverage, qualifications, and risk to ensure complete and accurate comparisons
• Identify value engineering opportunities, alternate means and methods, and cost-saving strategies
• Track, analyze, and communicate construction cost trends, labor availability, and material pricing impacts
• Collaborate with Operations and Project Management during project handoff to ensure a smooth transition from estimate to execution
• Mentor, train, and develop estimators, fostering professional growth and continuous improvement within the team

Qualifications

• Comprehensive knowledge of retail construction, including ground-up, tenant build-out, and remodel projects
• Bachelor's degree in Construction Management, Construction Engineering, Architecture or Business
• 8+ years of estimating experience within the retail construction industry, including leadership or management responsibilities
• Proven experience estimating projects typically ranging from $500K to $20M+ in revenue
• Strong proficiency in estimating software and electronic takeoff tools such as Bluebeam, PlanSwift, Procore, OST, etc.
• Ability to read, interpret, and analyze construction drawings, specifications, and contract documents
• Strong understanding of subcontractor scopes, general conditions, and risk allocation
• Demonstrated ability to resolve scope gaps, contract issues, and pricing discrepancies
• Exceptional communication skills with the ability to engage executives, field teams, subcontractors, suppliers, architects, engineers, and owners
• Willingness to attend pre-bid meetings, site walks, and client presentations as needed (travel may be required)

As an EEO employer, Place Services, Inc. is committed to providing all applicants and employees with equal access to employment opportunities, regardless of sex, race, age, color, national origin, disability, pregnancy, religion, marital status, veteran status, or any other characteristic protected by federal, state, or local law.

Senior Regional Construction Scheduler - $186K to $206K - Los Angeles, CA

Are you an experienced construction scheduling professional with deep expertise in CPM analysis and public works projects? Do you have the leadership skills and technical knowledge to guide project schedulers while ensuring complex construction programs stay on track?

If so, we invite you to apply for our Senior Regional Construction Scheduler role at PMCS Group, Inc.

The Role

The Senior Regional Construction Scheduler reports directly to the Sr. Construction Manager for Scheduling and Estimating. In this leadership position, you will oversee project schedulers and ensure that program and project schedules align with performance goals.

You will play a key role in reviewing contractor schedules, analyzing project impacts, and providing clear reporting to senior leadership.

Key Responsibilities

• Supervise Project Schedulers to ensure project timelines are achieved
• Review and analyze CPM schedules for accuracy and contract compliance
• Develop and maintain program and master schedules, including logic, milestones, and constraints
• Perform QA/QC reviews of contractor baseline and update submissions
• Conduct Critical Path and Earned Value analysis
• Complete Time Impact Analyses for change orders affecting project timelines
• Lead schedule negotiations related to delay settlements
• Interpret construction drawings to confirm scope and sequencing
• Provide written schedule review comments and executive-level reports
• Walk construction sites to validate schedule progress
• Communicate schedule updates in weekly and monthly status meetings
• Provide bi-monthly program schedule updates to leadership
• Forecast staffing needs and recommend adjustments to executive staff

About Our Company

At PMCS Group, Inc., we’ve built our reputation on over 70 years of combined industry experience and a team of 130+ professionals with deep expertise in construction, engineering, architecture, and inspection. We don’t just manage projects—we deliver them to the highest standard, on time and within budget.

We’re proud to partner with clients such as the Los Angeles Unified School District (LAUSD), Los Angeles Community College District (LACCD), California State University (CSU) campuses, and other public agencies. Our work has a direct impact on communities, improving educational facilities and public infrastructure across California.

The Benefits

• PTO: 120 hours annually (vacation/sick time), accrual starts on day one, available after 30 days.
• Holidays: 8 paid holidays per year, including New Year’s Day, Thanksgiving, and Christmas.
• Insurance: 100% coverage for employee’s Medical, Dental, and Vision, with additional costs for dependents and enhanced plans (Kaiser and Anthem Blue Cross options).
• 401(k) Savings Plan: 100% match up to 3%, plus 50% of the next 2% (fully vested immediately).
• Professional Development: Up to $1,000 annually for license/certification renewals and qualifying education.
• Parking: Parking provided, up to $100/month if applicable.

The Person

• Minimum 8 years of full-time professional construction scheduling experience with an Owner or General Contractor
• Experience in educational facilities or public works projects preferred
• Bachelor’s degree in Architecture, Engineering, Construction Management, or related field
• OR bachelor’s degree in another discipline with two additional years of relevant experience
• Advanced proficiency in Primavera (latest version) and MS Office Suite
• Strong written and verbal communication skills
• Excellent organizational and planning abilities
• Solid understanding of cost engineering, schedule forensics, and contract terms
• Ability to build effective working relationships with project teams and leadership

What’s Next

If you are ready to take the next step in your construction scheduling career, apply today and join a team where your expertise will make a measurable impact.

Construction Sales & Preconstruction Estimator

We are seeking a motivated and experienced Construction Sales & Preconstruction Estimator to drive business development efforts while leading the preconstruction process from concept through project kickoff. This role is ideal for someone with strong construction knowledge, excellent communication skills, and the ability to build lasting client relationships.

Required Skills & Qualifications

• Hands-on experience across multiple construction disciplines, including concrete, masonry, structural steel, carpentry, post-frame construction, and related trades
• Proven ability to negotiate and successfully close sales
• Strong verbal and written communication skills
• General computer proficiency and ability to manage digital documentation
• Ability to build, develop, and maintain long-term professional relationships
• Highly organized with the ability to manage multiple opportunities simultaneously and maintain accurate historical data
• Self-motivated with the ability to work independently and achieve performance goals
• Ability to read and interpret blueprints and construction drawings
• Valid driver’s license and ability to travel to meetings and job sites as needed

Key Responsibilities

• Actively network to develop and expand a new client base
• Attend social networking, public relations, and industry events
• Represent the company at trade shows and job fairs
• Present and sell company construction services to prospective and existing clients
• Participate in ongoing training and professional development
• Maintain consistent communication with clients and provide progress updates
• Demonstrate professionalism and exceptional customer service to past, current, and future clients
• Attend and conduct site walkthroughs with clients and subcontractors
• Solicit, evaluate, and prequalify subcontractors, including identifying new trade partners
• Develop conceptual budgets, detailed cost estimates, and final project pricing
• Prepare and write design-build proposals and detailed scopes of work for all subcontracting trades
• Lead and coordinate the full preconstruction process, including:
• Scheduling and project sequencing
• Budget development and cost control
• Preconstruction meetings and stakeholder coordination
• Collaboration with architects and designers
• Constructability reviews
• Scope identification and bid package development
• Permitting coordination
• Subcontractor qualification and selection
• Attend project meetings and serve as a liaison between owners, designers, subcontractors, and the construction team
• Ensure clear communication and alignment throughout the preconstruction and early construction phases
• teams.

The Director of Construction Technology plays a critical role in advancing the company’s use of technology across all business units and particularly within operations. This position serves as the bridge between construction operations, IT, and executive leadership — ensuring that technology solutions are effectively deployed, utilized, and continuously improved to support project delivery, operational efficiency, and data-driven decision making.

The Director of Construction Technology will maintain active awareness of emerging construction technologies, lead software training and adoption efforts, and provide first-line support for systems in use. This role is ideal for a candidate with a strong understanding of construction processes, a working knowledge of IT and system integrations, and a passion for applying technology to improve performance and collaboration across the organization.

This position reports to a Senior executive and will work closely with Project Management, Field Supervisors, Accounting, IT Staff, and the Executive Leadership team.

KEY RESPONSIBILITIES

Technology Leadership & Strategy

• Stay informed of industry technology trends, vendor developments, and emerging software capabilities relevant to construction operations.
• Advise leadership on opportunities for innovation, efficiency, and competitive advantage through technology adoption.
• Participate in strategic planning for technology roadmaps, integrations, and process automation.

System Management & Support

• Provide Level 1 helpdesk support for construction technology platforms, including issue resolution, troubleshooting, and escalation to vendors or IT as needed.
• Support implementation, configuration, and optimization of applicable technology solutions, software and systems.
• Ensure smooth coordination and communication between project and field personnel, IT staff, and software vendors.

Training & Adoption

• Develop and deliver training programs for project and office staff on relevant technologies and best practices.
• Create and maintain training materials, user guides, and process documentation.
• Promote a culture of technology adoption and continuous learning across the company.

Vendor & System Administration

• Assist in vendor management, including contract renewals, license tracking, support coordination, and performance evaluation.
• Coordinate system updates, release testing, and change management with IT and vendor teams.
• Help evaluate new software solutions, pilot programs, and system integrations.

Integration & Data Awareness

• Support efforts to integrate systems for seamless data flow between project management, corporate services, and field applications.
• Work with IT and business intelligence teams to improve data accessibility, reporting, and analytics.
• Understand and advocate for data integrity, ownership, and governance across platforms.

Collaboration & Field Engagement

• Collaborate daily with IT staff, project executives, project and field leaders, and senior management to align technology initiatives with operational goals.
• Conduct regular visits to company offices and job sites to assess technology use, identify opportunities for improvement, and provide hands-on support.

QUALIFICATIONS

Education

• College degree in Construction Management or related discipline preferred.
• Education or formal training in computer science, programming, or software development is a plus and may substitute for the college degree above with relevant operational experience.

Experience

• Minimum of 5 years of experience in the construction industry.
• At least 4 years in construction operations (field or project management experience preferred).
• 2–4 years of experience in a role involving technology solution management, system administration, or software implementation
• Experience in major software/systems transitions preferred.
• Experienced in the end-to-end implementation of scalable data lake solutions for enabling enhanced data accessibility and analytics for strategic business decisions.
• Developed interactive dashboards and reports using Power BI or equivalent.

Technical Competencies

• Familiarity with construction technology platforms such as Procore, Viewpoint, Autodesk, Bluebeam, etc.
• Understanding of IT operations, system integrations (APIs, data exchanges, middleware), and database principles.
• Proficiency in Microsoft 365 ecosystem (SharePoint, Teams, Power BI) and other common collaboration tools.
• Ability to train, communicate, and translate technical concepts to non-technical users.