What Is A Construction Framework Agreement Jobs in Usa

Position: Construction Superintendent 

Job Location: Greenwich CT, and Other Cities/ Towns 

Main Office: 250 Sargent Drive, New Haven, CT

Company: VASE Construction

Industry: Construction Management | Real Estate Development | General Contracting

Reports To: Project Manager, Vice President / Chief Estimator

Contact: ; 2

Company Description

VASE is a Construction Management firm overseeing renovations and new construction projects for public and private sectors, including government agencies, institutions, hospitals, and nonprofits. Learn more at

VASE is a leader in construction management, combining expertise with cutting-edge practices to deliver exceptional project results. The company is dedicated to exceeding industry standards, prioritizing efficiency and quality craftsmanship in all aspects of its operations. With a strong focus on innovation and client satisfaction, VASE Construction strives to streamline workflows and ensure the success of every project. Our commitment to excellence and a collaborative approach define who we are.

Role Description

We are seeking a dedicated Construction Superintendent for a full-time, on-site role in Greenwich, CT as well as other towns in Connecticut. The Construction Superintendent will oversee daily on-site operations, ensure projects are completed efficiently, and maintain high-quality standards. The responsibility includes supervising construction teams, coordinating schedules, enforcing safety regulations, managing budgets, and ensuring project timelines are met.

Qualifications

1. Experience in Construction Site Management and Construction Safety practices
2. 5+ Years Experience in a Superintendent role is required
3. Thorough understanding of construction processes, materials, and equipment
4. Proficiency in interpreting construction blueprints and documents
5. Proficiency in Excel, Word, Procore, or related Project Management software
6. Strong Project Management and Budgeting skills
7. Exceptional Organization Skills and the ability to manage multiple priorities effectively
8. Excellent communication and leadership abilities
9. Bachelor's degree in Construction Management, Engineering, Architecture, or related field preferred
10. Self-starter with the ability to multitask and work both independently and collaboratively.

Qualifications and Getting Started

Competitive salary commensurate with experience, plus benefits. To Apply: Send your resume and a brief cover letter to with the subject line “Construction Superintendent – [Your Name]”. For further assistance, call 2

Position: Payroll Specialist– Construction, Prevailing Wage & Multi-State Compliance

Location: Clackamas, OR (In-Office)

Pay: $70,000 – $90,000 annually (Salaried, Full-Time)

Schedule: Full-Time | In-Office | Business Casual (Company shirts provided)

Who We Are:

Our client is a construction-focused organization seeking an experienced Payroll Administrator to take primary ownership of payroll operations. This role supports a collaborative, process-driven team while allowing autonomy and accountability.

What You’ll Do:

• Own end-to-end payroll processing for construction and specialty contractor operations
• Process weekly and bi-weekly payrolls with a high level of accuracy
• Review, analyze, and correct employee time entry discrepancies
• Manage payroll adjustments, corrections, and off-cycle payrolls
• Ensure compliance with wage and hour regulations across applicable jurisdictions

What’s In It for You:

• Competitive salary with performance consideration
• High-ownership role with decision-making responsibility
• Collaborative support across accounting, HR, and operations
• Stable, full-time position in a structured construction environment

What You Need to Have:

• 3–5 years of payroll administration experience in construction or specialty contracting
• Hands-on prevailing wage experience
• Certified payroll experience for public works projects
• Multi-state payroll tax compliance experience
• Experience supporting employees working in multiple jurisdictions

The Musts:

• Prevailing wage classifications, fringe calculations, and wage determinations
• Certified payroll reporting for public works projects
• Multi-state payroll tax setup, reporting, and compliance
• Experience managing agency correspondence, audits, and filings
• Strong attention to detail and ability to independently resolve payroll discrepancies

Preferred:

• West Coast multi-state payroll experience (OR, WA, CA)
• Experience with construction timekeeping and payroll systems
• CPP certification

Next Steps:

Please respond with an updated resume!

Call Keyshawn at 36 |

OR

Call Isabel at 36 |

To schedule an interview or drop by for a walk-in interview!!

Address:

703 Broadway St Suite 690

Vancouver, 98660

What We Do:

SMK Services, Inc. (SMK) is a Construction Management and Engineering services consultancy based in Belmont, Massachusetts. Our clients include public agencies, professional engineering firms, general contractors, and subcontractors. We provide services in Project Management, Construction Build Strategy, Scheduling, Engineering Support, Construction Estimating, Claims Analysis and Field Services.

With a growing client base and an expanding range of services, SMK is seeking a Construction Project Manager to join our team in the Greater Boston Area.

Company Culture:

SMK is an exciting, collaborative, supportive environment where we take pride in the work we do and celebrate our collective success. We cultivate a strong sense of community, one where colleagues’ voices are valued, growth is encouraged, and leadership remains open and accessible. As our firm continues to expand, the successful candidate will help shape and strengthen SMK’s culture alongside us.

Opportunities for Growth:

SMK is a growing business that is continually evolving, creating meaningful opportunities for employees to grow alongside the company and advance their careers. We actively encourage and support colleagues in developing their careers in areas of the business and industry that align with their interests and passions. SMK offers ongoing professional development opportunities to broaden employee knowledge and ensure our team stays current with the latest industry practices and innovations.

Why SMK

SMK is intentionally built as a close-knit, highly collaborative team where people genuinely know, trust, and support one another. Our size allows for real relationships, open communication, and a workplace where individual contributions are visible and valued.

We pride ourselves on creating a warm, engaging, and supportive environment, one where experienced professionals can do their best work without bureaucracy or being lost in the crowd. Leadership is hands-on and accessible, collaboration is the norm, and we care deeply about both the quality of our work and the well-being of our team.

At SMK, you’re not just filling a role, you’re joining a group of professionals who respect each other’s expertise, enjoy working together, and are committed to growing the firm thoughtfully and sustainably.

The Role:

SMK is seeking an experienced Construction Project Manager to coordinate and supervise a diverse portfolio of contracts, primarily in the infrastructure field (highway/bridge or transit). The ideal candidate should have experience in Civil and Structural construction projects as well as having experience in general construction methodologies, disciplines and procedures. 

Ideal Candidate

The ideal candidate is an experienced construction professional with a strong background in civil and structural infrastructure projects who excels in a client-facing, consulting-oriented environment. They possess the ability to clearly visualize construction sequencing and phasing and to lead the development of thoughtful, practical build strategies that balance feasibility, risk, schedule, and cost.

They are comfortable managing project-level internal teams that may include estimators, schedulers, and assistant project managers, providing direction and coordination to ensure project objectives are executed efficiently and consistently. This individual can bring together work from different team members into clear, consistent deliverables.

The ideal candidate brings strong written communication skills and is experienced in independently authoring professional reports, technical memoranda, and narratives. They are equally adept at reviewing and quality-controlling the work of others, ensuring analytical rigor, clarity, and consistency before deliverables are issued to clients.

Highly organized and analytical, this individual can manage multiple projects and priorities while maintaining attention to detail. They communicate clearly and confidently, exercise sound professional judgment, and are comfortable representing SMK in discussions related to constructability, scheduling, cost, and risk.

They value collaboration, mentorship, and continuous improvement and are motivated by contributing to a close-knit, high-performing team. Adaptable and proactive, the ideal candidate is willing to step beyond their core responsibilities when needed to support colleagues, strengthen client relationships, and help grow the firm.

Key Responsibilities:

In this role, you will be responsible for a variety of tasks, including:

• Conducting site visits to enforce project requirements while recording project progress and assisting in the resolution of field issues.
• Preparing and reviewing submittals, RFIs and other official project correspondence.
• Attending and leading project issues, progress and change order negotiation meetings.
• Performing reviews of design documents for: (1) Compliance with project requirements; (2) Interdisciplinary coordination; (3) Analysis of conceptual feasibility and review for fatal flaws.
• Reviewing design plans and specifications to: (1) Propose means and methods build strategies with phasing and sequencing in report format; (2) Evaluate constructability, risk, delay, and cost overrun mitigation.
• Ability to develop and manage the development of: (1) Construction cost estimates; (2) Claim reviews and performing change order analysis; (3) Schedules using Primavera P6 and phasing methodology for construction activities; (4) Reviews on contractor schedule updates, time impact analyses and recovery efforts while proposing solutions to scheduling issues.
• Performing and presenting Risk Assessments and Value Engineering studies.
• Monitoring and tracking SMK project budgets.
• Assisting in the development and preparation of scope and fee proposals to clients.
• Supervising and mentoring entry level project management staff.

Key Attributes:

• Strong, intuitive understanding of construction principles, sequencing, and contractor means and methods.
• Ability to read, understand and interpret design drawings, specifications, and schedules.
• Exceptional written, verbal, and organizational skills.
• Demonstrated proficiency in independently authoring clear, well-structured analytical reports and narratives.
• Ability to think critically and think of solutions to complex problems in a dynamic environment.
• Sound judgment and confidence when engaging directly with clients.
• Ability to manage priorities and handle multiple tasks at once.
• Willingness to assist with other non-project management tasks as needed.

Qualifications:

• A Bachelor’s degree in Construction Management, Engineering, or a related field.
• A minimum of 7+ years of Project Management related experience in the civil heavy construction/transportation field.
• 5+ years experience with concrete placement, earth support systems, deep foundation construction, marine construction, structural steel erection, structural demolition, highway construction, drainage system construction, Interstate Highway traffic controls, environmental protection systems and field survey/layout.
• Required proficiency in Bluebeam and Microsoft Office 365.
• Experience with HCSS, Bid2Win, and/or Estimating Link
• Experience with Primavera P6 or Microsoft Project
• Valid driver’s license and access to a personal vehicle.
• Authorization to work in the United States.

Additional Employment Information:

• Full-time salaried position.
• Annual starting salary of $120,000 to $160,000, dependent on experience.
• Paid Time Off.
• Eleven days of holiday pay.
• Generous retirement plan contribution.
• Paid office parking.
• Cell phone allowance.
• Medical and dental insurance.
• Hybrid work structure with remote and in-office days based on workload, collaboration needs, client meetings, training, and experience level.
• Primary work location is office-based, with occasional site visits throughout New England.

Note to Applicants

This role requires significant experience in Civil (Heavy) Construction field, with Transportation experience preferred. We encourage applicants who closely match the qualifications outlined above to apply. Candidates whose experience does not align with the requirements will not be considered at this time.

Equal Employment Opportunity Statement:

SMK provides equal employment opportunity in employment and advancement for all persons regardless of race, religion, color, national origin, sex, sexual orientation, gender identity, age, status as a protected veteran and persons with a disability, at all employment levels, including the executive level. We do not and will not discriminate against any applicant or employee regardless of race, religion, color, national origin, sex, sexual orientation, gender identity, age, status as a protected veteran and persons with a disability for any position for which the applicant or employee is qualified. Such affirmative action shall apply to all employment practices, including, but not limited to hiring, upgrading, demotion or transfer, recruitment, recruitment advertising, layoff or termination, rates of pay or other forms of compensation, and selection for training, including apprenticeship and on-the-job training.

What We Do:

SMK Services, Inc. (SMK) is a Construction Management and Engineering services consultancy based in Belmont, Massachusetts. Our clients include public agencies, professional engineering firms, general contractors, and subcontractors. We provide services in Project Management, Construction Build Strategy, Scheduling, Engineering Support, Construction Estimating, Claims Analysis and Field Services.

With a growing client base and an expanding range of services, SMK is seeking a Senior Construction Scheduler to join our team in the Greater Boston Area.

Company Culture:

SMK is an exciting, collaborative, supportive environment where we take pride in the work we do and celebrate our collective success. We cultivate a strong sense of community, one where colleagues’ voices are valued, growth is encouraged, and leadership remains open and accessible. As our firm continues to expand, the successful candidate will help shape and strengthen SMK’s culture alongside us.

Opportunities for Growth:

SMK is a growing business that is continually evolving, creating meaningful opportunities for employees to grow alongside the company and advance their careers. We actively encourage and support colleagues in developing their careers in areas of the business and industry that align with their interests and passions. SMK offers ongoing professional development opportunities to broaden employee knowledge and ensure our team stays current with the latest industry practices and innovations.

Why SMK

SMK is intentionally built as a close-knit, highly collaborative team where people genuinely know, trust, and support one another. Our size allows for real relationships, open communication, and a workplace where individual contributions are visible and valued.

We pride ourselves on creating a warm, engaging, and supportive environment, one where experienced professionals can do their best work without bureaucracy or being lost in the crowd. Leadership is hands-on and accessible, collaboration is the norm, and we care deeply about both the quality of our work and the well-being of our team.

At SMK, you’re not just filling a role, you’re joining a group of professionals who respect each other’s expertise, enjoy working together, and are committed to growing the firm thoughtfully and sustainably.

The Role:

SMK is seeking a seasoned Senior Construction Scheduler to support and lead scheduling efforts for complex infrastructure and heavy civil design and construction projects, which may include transportation, rail, facilities, multi-modal, and large highway programs. The successful candidate will bring advanced Critical Path Method (CPM) scheduling expertise, deep hands-on experience with Primavera P6, and a proven ability to develop schedules and analyze, manage, and communicate schedule risks, constraints, and construction sequencing.

Ideal Candidate

The ideal candidate is someone who enjoys being trusted to take ownership of their work and is comfortable operating without heavy oversight. They are naturally curious, ask the right questions early, and think several steps ahead when developing or reviewing schedules.

They have the confidence to challenge assumptions, respectfully and constructively, and are comfortable explaining schedule logic, risks, and impacts to both technical and non-technical audiences. Rather than simply updating schedules, they focus on understanding why activities move, where risk is accumulating, and how decisions affect the overall program.

The ideal candidate values clarity, accuracy, and professionalism in written communication and takes pride in producing narratives and analyses that stand up to scrutiny. They are organized, pragmatic, and calm under pressure, with the judgment to prioritize what truly matters when multiple deadlines compete.

Finally, the ideal candidate is someone who appreciates working in a small, close-knit team. They are generous with their knowledge, supportive of colleagues, and motivated by contributing to a respectful, collaborative environment where people genuinely enjoy working together.

Key Responsibilities:

In this role, you will be responsible for a variety of tasks, including:

• Develop, maintain, and manage cost and resource-loaded CPM schedules using Primavera P6 and other scheduling tools.
• Prepare, update, and maintain design and Contract Time Determination schedules in accordance with contract requirements, client procedures, and industry best practices.
• Review designer and contractor schedule submittals, including baseline and re-baseline schedules, monthly updates, Time Impact Analyses, acceleration schedules, and recovery plans, for contractual and technical compliance.
• Perform independent time-impact analyses and review contractor requests for time extensions and delay-related submissions.
• Analyze schedule progress, critical paths, float consumption, and forecasted completion; identify at-risk activities and recommend mitigation strategies.
• Conduct site visits to active heavy civil construction projects to verify progress, document conditions, and perform or review schedule updates.
• Perform “what-if” schedule scenarios to assess impacts to milestones and overall project delivery.
• Prepare clear, well-documented technical reports, narratives, charts, and graphics summarizing schedule analyses and findings.
• Provide quality review of schedule-related reports prepared by others.
• Attend and participate in client progress and scheduling meetings; confidently present schedule updates, analyses, and recommendations.
• Coordinate closely with project managers, designers, contractors, and internal teams to resolve schedule issues and support effective project delivery.
• Support the maintenance and updating of SMK’s company-wide project and program schedules.

Key Attributes:

• Exceptional written, verbal, and organizational skills.
• Demonstrated proficiency in independently authoring clear, well-structured analytical reports and narratives.
• Ability to work independently while also collaborating effectively within a team.
• Strong, intuitive understanding of construction principles, sequencing, and contractor means and methods.
• Professional judgment and confidence to step into client-facing discussions.
• Flexibility with work location within Eastern Massachusetts.
• Willingness to step outside the core role to assist with periodic Project Management tasks as needed.

Qualifications:

A minimum of 6+ years of active civil (heavy) construction scheduling experience (transportation experience preferred), including:

• Developing and updating Contract Time Determination schedules with narrative reports.
• Reviewing and analyzing baseline schedules and monthly progress update schedules developed by others.

Required proficiency in:

• Primavera P6
• Microsoft Excel, Word, and Outlook

Experience with:

• Microsoft PowerPoint
• Bluebeam

Valid driver’s license and access to a personal vehicle

Authorization to work in the United States

Additional Employment Information:

• Full-time salaried position.
• Annual starting salary of $130,000 to $175,000, dependent on experience.
• Paid Time Off.
• Eleven days of holiday pay.
• Generous retirement plan contribution.
• Paid office parking.
• Cell phone allowance.
• Medical and dental insurance.
• Hybrid work structure with remote and in-office days based on workload, collaboration needs, client meetings, training, and experience level.
• Primary work location is office-based, with occasional site visits throughout New England.

Note to Applicants

This is a senior-level role requiring significant experience in Civil (Heavy) Construction scheduling, with Transportation experience preferred. We encourage applicants who closely match the qualifications outlined above to apply. Candidates whose experience does not align with the requirements will not be considered at this time.

Equal Employment Opportunity Statement:

SMK provides equal employment opportunity in employment and advancement for all persons regardless of race, religion, color, national origin, sex, sexual orientation, gender identity, age, status as a protected veteran and persons with a disability, at all employment levels, including the executive level. We do not and will not discriminate against any applicant or employee regardless of race, religion, color, national origin, sex, sexual orientation, gender identity, age, status as a protected veteran and persons with a disability for any position for which the applicant or employee is qualified. Such affirmative action shall apply to all employment practices, including, but not limited to hiring, upgrading, demotion or transfer, recruitment, recruitment advertising, layoff or termination, rates of pay or other forms of compensation, and selection for training, including apprenticeship and on-the-job training.

Construction Manager (WV - Civil Power Project)

Plan, direct, coordinate, or budget, usually through subordinate supervisory personnel, activities concerned with the construction and maintenance of structures, facilities, and systems. Participate in the conceptual development of a construction project and oversee its organization, scheduling, and implementation.

• Bachelor’s degree from an accredited college or university and 15 years’ related experience and/or training; or equivalent combination of education and experience
• Demonstrated ability to perform on progressively more complex projects
• Power project experience

JOB DUTIES AND TASKS:

• Schedule the project in logical steps and budget time required to meet deadlines.
• Determine labor requirements and dispatch workers to construction sites.
• Inspect and review projects to monitor compliance with building and safety codes, and other regulations.
• Interpret and explain plans and contract terms to administrative staff, workers, and clients, representing the owner or developer.
• Prepare contracts and negotiate revisions, changes and additions to contractual agreements with architects, consultants, clients, suppliers and subcontractors.
• Obtain all necessary permits and licenses. Direct and supervise workers.
• Study job specifications to determine appropriate construction methods.

• Develop and implement quality control programs.
• Take actions to deal with the results of delays, bad weather, or emergencies at construction site.
• Confer with supervisory personnel, owners, contractors, and design professionals to discuss and resolve matters such as work procedures, complaints, and construction problems.
• Plan, organize, and direct activities concerned with the construction and maintenance of structures, facilities, and systems.
• Investigate damage, accidents, or delays at construction sites, to ensure that proper procedures are being carried out.
• Evaluate construction methods and determine cost-effectiveness of plans, using computers.
• Direct acquisition of land for construction projects.

Construction Accountant

Location: Jacksonville, FL

Salary: $65,000 - $80,000

A growing commercial general contractor in Jacksonville is adding an Accountant to support their finance and accounting operations. This is a company with a strong reputation in the market, a collaborative team culture, and real momentum behind them. If you have a construction accounting background and enjoy working in a hands-on environment where your contributions are visible and valued, this is worth a close look.

What You'll Do

• Work alongside the Controller to support day-to-day accounting operations
• Manage job cost accounting across active projects
• Handle billing, receivables, accounts payable, and vendor invoices
• Review subcontractor payment applications and ensure timely payments
• Support month-end close processes and financial reporting

What You Bring

• 3+ years of accounting experience within commercial construction, either with a general contractor or subcontractor
• Hands-on experience with job cost accounting and subcontractor billing
• Proficiency in Oracle Textura, Procore, and Sage Intacct
• Strong attention to detail and the ability to manage multiple priorities in a fast-moving environment

What You'll Gain

• A stable, growing company with a strong culture and tenured leadership
• A visible role where your work directly supports project success
• Competitive compensation of $65,000 - $80,000 based on experience

At Framework, we keep it simple: we connect great people with great builders. We're not just filling seats - we're helping construction professionals find real opportunities with companies that value what they bring to the table. Our candidates trust us because we're honest, we follow through, and we never push roles that aren't the right fit. We take the time to understand where you're coming from and where you want to go.

The builders we represent are more than just clients to us. Many of them are friends and longtime partners. If we wouldn't feel confident working for them ourselves, we wouldn't introduce them to the people who trust us with their careers.

On the flip side, our clients count on us to bring high-quality people who are the real deal - both in skill and character. They'll tell you we just get it. We're proud to be the kind of recruiters who do what's right, not what's easy, and we make sure it's a win for everyone involved.

The Construction Scheduler & BIM Modeler is a hybrid role responsible for integrating schedule development with model-based coordination to improve project predictability, sequencing, and execution. This position supports projects from preconstruction through closeout by combining Critical Path scheduling with BIM coordination, clash detection, and 4D planning.

This role works closely with Project Managers, Superintendents, Preconstruction, and trade partners to ensure projects are delivered on time, fully coordinated, and aligned with company standards for safety, quality, and accountability.

Essential Functions/Job Responsibilities:

To perform this job successfully, an individual must be able to perform each essential duty satisfactorily, with or without special accommodation.

Key Responsibilities

Scheduling (CPM / Project Controls)

• Develop and maintain baseline CPM schedules during preconstruction
• Build detailed construction schedules including phasing and sequencing
• Identify critical path activities and long-lead procurement items
• Lead schedule coordination meetings with internal teams and subcontractors
• Provide bi-weekly or monthly schedule updates
• Develop recovery schedules when delays occur
• Perform time impact analysis when needed
• Create executive-level schedule reporting dashboards
• Support claims documentation related to schedule impacts

BIM Modeling & Coordination

• Develop and maintain 3D BIM models for coordination and planning
• Perform clash detection and facilitate trade coordination meetings
• Integrate schedule into model for 4D sequencing visualization
• Support quantity takeoffs and model-based estimating
• Produce coordination drawings and assist with shop drawing review
• Maintain BIM standards and naming conventions
• Assist field teams with model access and real-time updates
• Support as-built modeling and closeout documentation

Qualifications

• Bachelor’s degree in construction management, Engineering, Architecture, or related field (preferred)
• 3–5 years of commercial construction experience
• Proficiency in:
• Primavera P6 or Microsoft Project
• Autodesk Revit
• Strong understanding of construction sequencing and field operations
• Ability to read and interpret plans and specifications
• Experience with healthcare or complex commercial coordination preferred
• Excellent communication and analytical skills

This job description outlines the primary and recurring responsibilities of this position. It is not intended to be an exhaustive list of all duties, responsibilities, or tasks that may be required. The individual in this role will regularly perform additional related assignments, special projects, and other duties as directed by company leadership, including the Director of Operations, Preconstruction Manager, and/or other designated supervisors.

South Carolina is an Employment-At-Will state. This job description does not constitute an employment agreement or contract. Management reserves the exclusive right to modify, revise, or update this job description at any time, with or without notice.

Now Hiring: Contracts Administrator – Construction

We are seeking a detail-oriented Contracts Administrator to support the preparation, review, and administration of contract documents for active construction projects. This role plays a critical part in managing contractual risk, ensuring compliance, and supporting project and executive teams throughout the project lifecycle. The ideal candidate has strong contract knowledge, excellent communication skills, and experience working in or alongside the construction industry.

Position Summary

The Contracts Administrator assists with reviewing bid documents, contracts, subcontracts, insurance and bonding requirements, and other project-related agreements. This position works closely with Operations, Project Managers, Executives, and Cost Engineering to identify risks, track contractual obligations, and maintain accurate documentation.

Qualifications

• Associate’s Degree in a related field required; coursework in Business Law is a plus
• 3–5 years of experience in contract preparation and administration
• Construction industry experience preferred
• Strong business acumen with exceptional attention to detail and accuracy
• Excellent written, verbal, reading comprehension, and editing skills
• Highly organized, efficient, and able to multitask and meet deadlines
• Ability to maintain confidentiality and exercise discretion at all times
• Proficient in Microsoft Word and Excel; Adobe tools and document editing experience required
• Strong problem-solving skills with the ability to identify and resolve issues quickly

Key Responsibilities

• Review bid and contract documents prior to RFP or proposal submission, including:
• Contract terms and general conditions
• Owner direct purchase and sales tax exemption requirements
• Insurance and wrap-up programs (OCIP/CCIP)
• Bonding requirements
• Certified payroll, prevailing wage, and Davis-Bacon requirements
• Credit investigations and project risk assessments
• Perform initial contract reviews and identify potential risks or unfavorable terms
• Compile and communicate contract comments to Operations, Project Managers, and Cost Engineering
• Maintain documentation of all contract markups and approvals
• Organize, attend, and document internal contract review meetings
• Coordinate bonds and insurance certificates as required
• Track execution status of contracts and follow up on outstanding agreements
• Manage subcontract preparation, execution, tracking, and documentation
• Provide administrative support to corporate officers as needed
• Interface with executives to assist with fleet program management
• Perform other related duties as assigned

Supervisory Responsibility

• None

Physical Requirements

• Primarily sedentary office role
• Occasional lifting of files or office materials up to 20 pounds
• Ability to file, bend, stand, and use standard office equipment

Equal Opportunity Employer

We are an Equal Opportunity and Affirmative Action Employer and a Drug-Free Workplace. All qualified applicants will receive consideration for employment without regard to race, color, religion, sex, gender identity, sexual orientation, national origin, disability, veteran status, or any other protected status.

If you thrive in a fast-paced construction environment and enjoy contract analysis, organization, and collaboration, we encourage you to apply.

Job Title: Commercial Construction Project Manager

Location: Colorado Springs, Colorado

Company: Matukat Construction

Salary Range: $100,000–$135,000

Commercial Construction Project Manager 

Matukat Construction 

About Matukat Construction 

Matukat Construction is a relationship-driven commercial general contractor known for delivering high-quality projects through strong leadership, collaboration, and accountability. Our success is built on trust—with our clients, trade partners, and internal teams—and on developing people who take pride in building great work the right way. 

We are seeking an experienced Commercial Construction Project Manager to lead complex projects from preconstruction through closeout while upholding Matukat’ s commitment to excellence, integrity, and teamwork. 

Position Summary 

The Commercial Construction Project Manager is fully responsible for the successful delivery of projects ranging from $10M–$100M, across multiple delivery methods and market sectors. This role requires strong leadership, financial acumen, contract management expertise, and the ability to build and sustain effective relationships with owners, designers, subcontractors, and internal teams. 

The Project Manager serves as the primary point of accountability for cost, schedule, quality, safety, risk management, and team development. 

Key Responsibilities 

Building Effective Relationships 

• Partner with Estimating to ensure a seamless handoff from preconstruction to operations. 
• Prioritize a strong working relationship with the Lead Superintendent and actively support field operations. 
• Build and maintain productive relationships with subcontractor Project Managers; proactively manage underperforming subcontractors. 
• Maintain strong relationships with Design Team Leads and support proactive business development efforts. 
• Act as the primary point of contact with the Owner’s Representative, building trust and positioning Matukat for repeat work. 
• Confidently manage principals’ meetings, subcontractor defaults, supplements, and replacements. 
• Keep business development and networking top of mind throughout the project lifecycle. 
• Demonstrate strong self-awareness, continuous self-improvement, and a commitment to developing both leadership and people skills. 

Contracts & Preconstruction 

• Maintain 100% responsibility for project buyout, including creation and execution of a Buyout Matrix (“90 in 90”). 
• Have a detailed working understanding of subcontractor scopes and be able to draft subcontractor contract agreements. 
• Review, understand, and communicate Owner (Prime) Contract requirements to the full project team. 
• Collaborate with Estimators during preconstruction to manage design phases, establish the GMP, and define General Conditions. 
• Successfully manage projects with budgets ranging from $10M–$100M. 

Cost Control & Financial Management 

• Maintain full responsibility for cost control and forecasting, submitting accurate monthly cost reports. 
• Maintain accurate and current PCI logs (internal and external) and identify cost risks during monthly reconciliations. 
• Ensure General Requirements (GRs) and General Conditions (GCs) are fully captured in all applicable change orders. 
• Resolve the majority of external PCIs through clear documentation and timely Owner Change Orders. 
• Oversee all pay applications and invoicing in coordination with Project Administration. 
• Maintain positive project cash flow and leverage financial tools to support subcontractor negotiations. 

Risk, Schedule, Quality & Safety Management 

• Recognize schedule as the project’s primary risk and provide proactive, meaningful scheduling input. 
• Ensure weekly and monthly schedule updates are accurate and issued on time. 
• Lead procurement meetings to align material deliveries with the project schedule. 
• Negotiate, prepare, and defend the majority of potential project claims. 
• Identify and address problematic subcontractors early and effectively. 
• Ensure QA/QC plans are implemented and actively participate in quality oversight. 
• Participate in safety planning and execution; uphold and enforce jobsite safety standards. 
• Work closely with Superintendents and field teams to maintain compliance with site safety plans. 
• Foster a positive, professional, and collaborative project team environment. 

Staff Management & Leadership 

• Develop and maintain the project responsibility matrix and organizational chart. 
• Monitor staff workloads and reassign tasks to ensure balance and efficiency. 
• Lead weekly project team meetings and track action items through a project hot list. 
• Directly manage and mentor APMs, PEs, and Interns, supporting career growth and development. 
• Actively mitigate staff turnover through strong leadership, communication, and support. 
• Build team morale and maximize individual and team performance. 

Qualifications 

• Bachelor’s degree in Construction Management, Engineering, or related field (or equivalent experience). 
• Proven experience managing commercial construction projects in the $10M–$100M range. 
• Strong understanding of contracts, cost control, scheduling, and risk management. 
• Demonstrated leadership and ability to develop high-performing project teams. 
• Excellent communication, negotiation, and organizational skills. 
• Commitment to safety, quality, and continuous improvement. 

Why Join Matukat Construction 

We are a team that supports one another and celebrates shared accomplishments. At Matukat, you are not just an employee—you are part of a community dedicated to building a better future. 

• A Culture of Care: We foster a supportive and inclusive environment where your well-being and professional growth are top priorities. 
• Purpose-Driven Work: See the direct impact of your contributions on projects that matter to the community. 
• Opportunities for Growth: We are committed to your professional development and provide pathways for advancement within the company. 

Benefits 

Matukat Construction offers a competitive benefits package designed to support the health, well-being, and long-term success of our team members. Benefits for eligible full-time employees include: 

• Paid Time Off (PTO) and paid holidays 
• Health Insurance coverage options 
• 401(k) Retirement Plan with company match 

Benefit eligibility and details vary by position and employment status. 

Ready to Build With Us? 

If you are ready to apply your skills to a role with meaning and join a company that truly values its people, we encourage you to apply. 

Let’s build something great together. 

 Apply at:    

Stansell is seeking a talented Construction Project Manager in the Michigan region to join our team!

POSITION IS REMOTE BUT CANDIDATE MUST RESIDE IN MI AND BE ABLE TO TRAVEL.

Stansell is a rapidly growing, WBE certified, general contractor specializing in commercial construction services across the Southeast United States. We focus on serving clients in the commercial market with emphasis on the following project types: restaurant dining and quick service food. The ideal candidate for this role is a career-minded individual with a customer service focus, has high energy, and is detail oriented. This candidate will have an analytical mind and great organizational skills.

Responsibilities

• Leads an environment of Respect, Commitment, Teamwork, Integrity, Reliability, and Professionalism.
• Collaborating with engineers, architects, owners, etc. to determine the specifications of the project
• Organize and oversee construction procedures and ensure they are completed in a timely and efficient manner.
• Negotiating contracts with external vendors to reach profitable agreements
• Obtain permits and licenses from appropriate authorities
• Determine needed resources (manpower, equipment and materials) from start to finish with attention to budgetary limitations
• Coordinate with on-site Superintendent to plan all construction operations and schedule intermediate phases to ensure deadlines will be met
• Secure subcontractors for specific trade needs
• Evaluate progress and apply necessary changes to achieve planned goals
• Leads overall project closeout process
• Ensure adherence to all health and safety standards and report issues

Requirements and Skills

• Minimum 3 years commercial retail construction project management, quick service restaurant experience HIGHLY preferred.
• In-depth understanding of construction procedures and material and project management principles
• Familiarity with construction/ project management software, Sage 100 and Procore
• Outstanding communication and negotiation skills
• Excellence with organizational and time-management skills is a must
• A team player with leadership abilities
• BS/BA in engineering, building science, or construction will be an advantage
• Strong PC skills with a working knowledge of including but not limited to MS Excel, MS Word, MS Office, and Outlook.
• Must have strong knowledge and appreciation of construction safety processes and ability to enforce the project safety plan

We offer a fast-paced environment with excellent competitive pay and excellent benefits:

• Employer subsidized medical
• Dental, Vision, Life
• 401(k) retirement plan with Company Matching Funds
• Company credit card for travel and job-related expenses
• Vehicle allowance
• Wellness Program
• Cell Phone Allowance
• Paid Time Off (PTO)
• Company Shirt Allowance

Qualified applicants will receive consideration for employment without regard to race, color, religion, sex, national origin, citizenship status, sexual orientation, gender identity, disability or protected veteran status.