Bell Construction Jobs in Usa

Our client, a national specialty contractor focused on commercial construction, is seeking a Job Control Technician / Associate Project Manager to join their Kansas City branch.

This role is responsible for tracking labor productivity, job costs, and project progress across multiple projects, providing critical information to field and office teams to support timely decisions and project execution. This position is open due to company growth and the need for enhanced project cost management across the branch.

In this role, you’ll split your time between visiting commercial construction jobsites within the Kansas City area and working in the office to track job progress, labor productivity, and cost-to-complete estimates. While onsite, you’ll walk active projects with field leadership, review construction drawings, quantify completed scope, identify potential schedule or cost issues, and report on manpower gaps. Back in the office, you’ll update project management and accounting systems, prepare job control reports, and collaborate with Construction Managers, Account Managers, and branch leadership to ensure projects stay on track financially and operationally.

If you’re looking to build a career in construction project management, whether you come from a field construction background or are seeking to transition into an office-based project role, we encourage you to apply.

Key Responsibilities:

• Break down projects into work packages and cost codes prior to project start to enable efficient tracking
• Set up and maintain project information in accounting and project management systems
• Track labor productivity, job progress, and estimated cost-to-complete on open projects
• Visit active jobsites to monitor work, review drawings, perform reverse takeoffs, and identify scope, schedule, or manpower issues
• Prepare job control and cost performance reports for branch leadership and project teams
• Collaborate with Construction Managers, Account Managers, and branch leadership to resolve project issues
• Support documentation and tracking of change orders, delays, and project adjustments
• Apply safety best practices while on jobsites, navigating varied terrain, climbing ladders, and working in weather conditions

Requirements:

• High school diploma (or equivalent) with relevant field construction experience, OR Associate’s/Bachelor’s degree in a discipline with strong analytical, organizational, or communication skills
• Ability to read and interpret construction drawings
• Strong organizational and analytical skills with attention to detail
• Proficient in Microsoft Excel and Word; familiarity with project management software a plus
• Excellent written and verbal communication skills
• Valid driver’s license and reliable transportation
• Ability to travel frequently within the Kansas City area to multiple jobsites
• OSHA-10 Certification is a plus
• Experience with Autodesk Navisworks, BIM Track, or Estimating software
• Field construction experience or exposure to construction professionals

Salary: $65,000-70,000 base + annual bonus

Location: Kansas City, MO

Travel: Frequent travel within Kansas City area job sites

Benefits: Mileage/Car Allowance, Medical, Dental, Vision, 401(k) with match, PTO, Life and AD&D, Short- and Long-Term Disability, annual performance review, and structured mentorship program.

If this sounds like your background, please apply and one of our recruiters will be in touch.

Follow us on LinkedIn:

The Virtual Design and Construction (VDC) manager is a fast-paced position overseeing the planning and coordination of a variety of projects. The VDC Manager will lead all aspects of Harvey Cleary’s VDC construction initiatives across the company, ensuring projects are taken from the design phase and digitally modeled to solve coordination issues before the start of field installation.

This role will function as a subject matter expert for VDC processes and technology innovation platforms, ensuring that building Information modeling (BIM) coordination is utilized throughout the Harvey Cleary organization. This individual embodies Harvey Cleary’s values of integrity, quality, and innovation in their work and interactions with team members and project stakeholders. The VDC Manager will report to the Director of Technology while supporting various operations teams in the successful VDC delivery of projects.

Supervisory Responsibilities

• In collaboration with the Director of Technology, recruit, interview, hire, and train new staff in the VDC department.
• Oversee the daily workflow of the department.
• Provide constructive and timely performance evaluations of VDC team members.

Duties and Responsibilities

• Manage deployment of VDC initiatives and VDC technology platforms.
• Train, educate, and mentor VDC engineers as well as project staff on current BIM/VDC processes and services.
• Lead in the compliance, development, and refinement of the Harvey Cleary BIM Execution Plan (BEP) and adhere to the Harvey Cleary BIM standards and refinement of future iterations.
• Create Building Information Models (BIM) of varying Levels of Development (LOD) and dimensions (3/4/5/6D) to meet project requirements.
• Identify, champion, and implement innovative improvements in model-based processes and technologies that improve project delivery.
• Perform clash detection of federated models and lead coordination efforts with project teams, clients, consultants, subcontractors, manufacturers, etc.
• Create 4D and physical models to inform construction planning, site logistics, constructability reviews, lift plans, safety, quality control/assurance, etc.
• Support preconstruction teams in the development of 3D quantity takeoffs.
• Provide technical expertise to assist business development and marketing teams in pursuit efforts, including interview preparation and assistance with site logistics, physical models and 4D site logistics models.
• Participate in weekly team meetings to review the BIM coordination process, as needed, in collaboration with project teams.
• Collaborate with project teams to ensure the VDC team is producing construction documents that are efficient, accurate, and appropriate for the team’s use in their coordination efforts.
• Mentor and guide the VDC department staff to further the value of the department and it’s day to day responsibilities.
• Other duties as assigned.

Qualifications:

• Bachelor’s degree in architecture, engineering, construction management, or a related field, or equivalent training/experience.
• 5+ years AEC industry experience in VDC role, preferably in the construction industry.
• Strong knowledge of MEP industry, CAD modeling, construction scheduling, and time managment
• Proven leadership qualities from previous project roles.
• Excellent written and oral communication skills and ability to interact effectively with all levels of employees.
• Must be a motivated self-starter and the ability to handle multiple tasks.
• Ability to function as BIM/VDC project manager on assigned projects.
• Ability to develop and implement BIM/VDC processes on assigned projects.
• Ability to implement BIM/VDC field construction processes.
• Ability to manage multiple projects and priorities simultaneously.
• Ability to work well both in a team environment and on individual assignments.
• Ability to work with autonomy, think critically, and use professional judgment.
• Proficiency with modeling, CAD, and coordination software’s (Revit, Navisworks, AutoCAD, SketchUp, Procore, etc.).
• Proven experience leading BIM coordination meetings with a variety of stakeholders.
• Proficiency reading and interpreting construction drawings, specifications, and schedules.
• Proficiency with Microsoft 365 and various video conferencing platforms (Teams, Zoom, Webex, etc.).

Physical Requirements

• Prolonged periods of sitting and working on a computer.
• Willingness to communicate.
• May be required to lift, carry, and move up to 15 lbs.

Prospective employees must be able to pass a criminal background check and random drug screens.

The Director of Construction Technology plays a critical role in advancing the company’s use of technology across all business units and particularly within operations. This position serves as the bridge between construction operations, IT, and executive leadership — ensuring that technology solutions are effectively deployed, utilized, and continuously improved to support project delivery, operational efficiency, and data-driven decision making.

The Director of Construction Technology will maintain active awareness of emerging construction technologies, lead software training and adoption efforts, and provide first-line support for systems in use. This role is ideal for a candidate with a strong understanding of construction processes, a working knowledge of IT and system integrations, and a passion for applying technology to improve performance and collaboration across the organization.

This position reports to a Senior executive and will work closely with Project Management, Field Supervisors, Accounting, IT Staff, and the Executive Leadership team.

KEY RESPONSIBILITIES

Technology Leadership & Strategy

• Stay informed of industry technology trends, vendor developments, and emerging software capabilities relevant to construction operations.
• Advise leadership on opportunities for innovation, efficiency, and competitive advantage through technology adoption.
• Participate in strategic planning for technology roadmaps, integrations, and process automation.

System Management & Support

• Provide Level 1 helpdesk support for construction technology platforms, including issue resolution, troubleshooting, and escalation to vendors or IT as needed.
• Support implementation, configuration, and optimization of applicable technology solutions, software and systems.
• Ensure smooth coordination and communication between project and field personnel, IT staff, and software vendors.

Training & Adoption

• Develop and deliver training programs for project and office staff on relevant technologies and best practices.
• Create and maintain training materials, user guides, and process documentation.
• Promote a culture of technology adoption and continuous learning across the company.

Vendor & System Administration

• Assist in vendor management, including contract renewals, license tracking, support coordination, and performance evaluation.
• Coordinate system updates, release testing, and change management with IT and vendor teams.
• Help evaluate new software solutions, pilot programs, and system integrations.

Integration & Data Awareness

• Support efforts to integrate systems for seamless data flow between project management, corporate services, and field applications.
• Work with IT and business intelligence teams to improve data accessibility, reporting, and analytics.
• Understand and advocate for data integrity, ownership, and governance across platforms.

Collaboration & Field Engagement

• Collaborate daily with IT staff, project executives, project and field leaders, and senior management to align technology initiatives with operational goals.
• Conduct regular visits to company offices and job sites to assess technology use, identify opportunities for improvement, and provide hands-on support.

QUALIFICATIONS

Education

• College degree in Construction Management or related discipline preferred.
• Education or formal training in computer science, programming, or software development is a plus and may substitute for the college degree above with relevant operational experience.

Experience

• Minimum of 5 years of experience in the construction industry.
• At least 4 years in construction operations (field or project management experience preferred).
• 2–4 years of experience in a role involving technology solution management, system administration, or software implementation
• Experience in major software/systems transitions preferred.
• Experienced in the end-to-end implementation of scalable data lake solutions for enabling enhanced data accessibility and analytics for strategic business decisions.
• Developed interactive dashboards and reports using Power BI or equivalent.

Technical Competencies

• Familiarity with construction technology platforms such as Procore, Viewpoint, Autodesk, Bluebeam, etc.
• Understanding of IT operations, system integrations (APIs, data exchanges, middleware), and database principles.
• Proficiency in Microsoft 365 ecosystem (SharePoint, Teams, Power BI) and other common collaboration tools.
• Ability to train, communicate, and translate technical concepts to non-technical users.

What We Do:

SMK Services, Inc. (SMK) is a Construction Management and Engineering services consultancy based in Belmont, Massachusetts. Our clients include public agencies, professional engineering firms, general contractors, and subcontractors. We provide services in Project Management, Construction Build Strategy, Scheduling, Engineering Support, Construction Estimating, Claims Analysis and Field Services.

With a growing client base and an expanding range of services, SMK is seeking a Senior Construction Scheduler to join our team in the Greater Boston Area.

Company Culture:

SMK is an exciting, collaborative, supportive environment where we take pride in the work we do and celebrate our collective success. We cultivate a strong sense of community, one where colleagues’ voices are valued, growth is encouraged, and leadership remains open and accessible. As our firm continues to expand, the successful candidate will help shape and strengthen SMK’s culture alongside us.

Opportunities for Growth:

SMK is a growing business that is continually evolving, creating meaningful opportunities for employees to grow alongside the company and advance their careers. We actively encourage and support colleagues in developing their careers in areas of the business and industry that align with their interests and passions. SMK offers ongoing professional development opportunities to broaden employee knowledge and ensure our team stays current with the latest industry practices and innovations.

Why SMK

SMK is intentionally built as a close-knit, highly collaborative team where people genuinely know, trust, and support one another. Our size allows for real relationships, open communication, and a workplace where individual contributions are visible and valued.

We pride ourselves on creating a warm, engaging, and supportive environment, one where experienced professionals can do their best work without bureaucracy or being lost in the crowd. Leadership is hands-on and accessible, collaboration is the norm, and we care deeply about both the quality of our work and the well-being of our team.

At SMK, you’re not just filling a role, you’re joining a group of professionals who respect each other’s expertise, enjoy working together, and are committed to growing the firm thoughtfully and sustainably.

The Role:

SMK is seeking a seasoned Senior Construction Scheduler to support and lead scheduling efforts for complex infrastructure and heavy civil design and construction projects, which may include transportation, rail, facilities, multi-modal, and large highway programs. The successful candidate will bring advanced Critical Path Method (CPM) scheduling expertise, deep hands-on experience with Primavera P6, and a proven ability to develop schedules and analyze, manage, and communicate schedule risks, constraints, and construction sequencing.

Ideal Candidate

The ideal candidate is someone who enjoys being trusted to take ownership of their work and is comfortable operating without heavy oversight. They are naturally curious, ask the right questions early, and think several steps ahead when developing or reviewing schedules.

They have the confidence to challenge assumptions, respectfully and constructively, and are comfortable explaining schedule logic, risks, and impacts to both technical and non-technical audiences. Rather than simply updating schedules, they focus on understanding why activities move, where risk is accumulating, and how decisions affect the overall program.

The ideal candidate values clarity, accuracy, and professionalism in written communication and takes pride in producing narratives and analyses that stand up to scrutiny. They are organized, pragmatic, and calm under pressure, with the judgment to prioritize what truly matters when multiple deadlines compete.

Finally, the ideal candidate is someone who appreciates working in a small, close-knit team. They are generous with their knowledge, supportive of colleagues, and motivated by contributing to a respectful, collaborative environment where people genuinely enjoy working together.

Key Responsibilities:

In this role, you will be responsible for a variety of tasks, including:

• Develop, maintain, and manage cost and resource-loaded CPM schedules using Primavera P6 and other scheduling tools.
• Prepare, update, and maintain design and Contract Time Determination schedules in accordance with contract requirements, client procedures, and industry best practices.
• Review designer and contractor schedule submittals, including baseline and re-baseline schedules, monthly updates, Time Impact Analyses, acceleration schedules, and recovery plans, for contractual and technical compliance.
• Perform independent time-impact analyses and review contractor requests for time extensions and delay-related submissions.
• Analyze schedule progress, critical paths, float consumption, and forecasted completion; identify at-risk activities and recommend mitigation strategies.
• Conduct site visits to active heavy civil construction projects to verify progress, document conditions, and perform or review schedule updates.
• Perform “what-if” schedule scenarios to assess impacts to milestones and overall project delivery.
• Prepare clear, well-documented technical reports, narratives, charts, and graphics summarizing schedule analyses and findings.
• Provide quality review of schedule-related reports prepared by others.
• Attend and participate in client progress and scheduling meetings; confidently present schedule updates, analyses, and recommendations.
• Coordinate closely with project managers, designers, contractors, and internal teams to resolve schedule issues and support effective project delivery.
• Support the maintenance and updating of SMK’s company-wide project and program schedules.

Key Attributes:

• Exceptional written, verbal, and organizational skills.
• Demonstrated proficiency in independently authoring clear, well-structured analytical reports and narratives.
• Ability to work independently while also collaborating effectively within a team.
• Strong, intuitive understanding of construction principles, sequencing, and contractor means and methods.
• Professional judgment and confidence to step into client-facing discussions.
• Flexibility with work location within Eastern Massachusetts.
• Willingness to step outside the core role to assist with periodic Project Management tasks as needed.

Qualifications:

A minimum of 6+ years of active civil (heavy) construction scheduling experience (transportation experience preferred), including:

• Developing and updating Contract Time Determination schedules with narrative reports.
• Reviewing and analyzing baseline schedules and monthly progress update schedules developed by others.

Required proficiency in:

• Primavera P6
• Microsoft Excel, Word, and Outlook

Experience with:

• Microsoft PowerPoint
• Bluebeam

Valid driver’s license and access to a personal vehicle

Authorization to work in the United States

Additional Employment Information:

• Full-time salaried position.
• Annual starting salary of $130,000 to $175,000, dependent on experience.
• Paid Time Off.
• Eleven days of holiday pay.
• Generous retirement plan contribution.
• Paid office parking.
• Cell phone allowance.
• Medical and dental insurance.
• Hybrid work structure with remote and in-office days based on workload, collaboration needs, client meetings, training, and experience level.
• Primary work location is office-based, with occasional site visits throughout New England.

Note to Applicants

This is a senior-level role requiring significant experience in Civil (Heavy) Construction scheduling, with Transportation experience preferred. We encourage applicants who closely match the qualifications outlined above to apply. Candidates whose experience does not align with the requirements will not be considered at this time.

Equal Employment Opportunity Statement:

SMK provides equal employment opportunity in employment and advancement for all persons regardless of race, religion, color, national origin, sex, sexual orientation, gender identity, age, status as a protected veteran and persons with a disability, at all employment levels, including the executive level. We do not and will not discriminate against any applicant or employee regardless of race, religion, color, national origin, sex, sexual orientation, gender identity, age, status as a protected veteran and persons with a disability for any position for which the applicant or employee is qualified. Such affirmative action shall apply to all employment practices, including, but not limited to hiring, upgrading, demotion or transfer, recruitment, recruitment advertising, layoff or termination, rates of pay or other forms of compensation, and selection for training, including apprenticeship and on-the-job training.

Summary

The Highway Lighting & Traffic Signal Foreman leads field crews on highway construction projects, ensuring work is completed safely, efficiently, and according to project plans and specifications. This role oversees daily operations, coordinates crews and equipment, and supports project managers and superintendents in delivering high-quality infrastructure projects.

Key Responsibilities

• Supervise and coordinate daily work activities of construction crews.
• Operate heavy equipment such as drill rigs, backhoes, ditch witch, rock saws, bucket trucks, and other machinery.
• Read and interpret construction plans and layouts to guide project execution.
• Measure and mark construction areas to ensure accurate placement of structures and utilities.
• Load, unload, and transport construction materials, tools, and equipment.
• Assist with installation of traffic control devices, scaffolding, barricades, and temporary structures.
• Coordinate materials, equipment, and labor needed to complete job tasks.
• Monitor job site safety and ensure compliance with safety procedures and regulations.
• Inspect work progress and job sites to ensure specifications and quality standards are met.
• Record and report production, equipment usage, and crew activity.
• Assist crew members with construction activities as needed.

Qualifications

• Minimum 3 years of highway or heavy civil construction experience.
• At least 1 year of supervisory or foreman experience preferred.
• Ability to read and interpret construction plans and specifications.
• Valid Texas driver’s license required.

Preferred Qualifications

• Previous highway lighting or traffic signal construction experience.
• Commercial Driver’s License (CDL).
• Bilingual Spanish/English.

Work Environment & Physical Requirements

• Work performed primarily outdoors in highway and construction environments.
• Frequent operation of heavy equipment and hand tools.
• Ability to lift up to 50 lbs and occasionally exert force up to 100 lbs.
• Standing, walking, climbing, bending, and kneeling for extended periods.
• Regular exposure to weather conditions, dust, noise, and construction hazards.
• Required use of personal protective equipment (PPE).

Job Title: Senior Construction Site Supervisor 

Location: Los Angeles, California

Job Type: Full-Time

Experience Level: 10 years Minimum Construction Experience

Compensation: $120,000 - $155,000

Reports To: Project Executive

About Us:

We are a fast-growing construction firm known for delivering exceptional quality and precision in high-end environments. Our specialty lies in luxury retail boutiques, upscale restaurants, flagship showrooms, premium hospitality spaces and custom residential. As we continue to expand, we are looking for a detail-oriented site supervisors.

Job Summary:

We are immediately seeking an experienced Senior Construction Site Supervisor with a minimum of ten (10) years of light commercial and tenant improvement supervision experience, specifically within retail and restaurant environments.

The Senior Construction Site Supervisor is responsible for the daily on-site leadership of assigned projects, ensuring schedules, quality standards, safety compliance, subcontractor performance, and site organization meet company expectations. This role is critical to delivering projects on time, on budget, and at the level of quality our clients expect.

Key Responsibilities:

Project Oversight & Coordination

• Read and interpret full construction drawing sets daily, maintaining a thorough understanding of all project details.
• Proactively manage and push schedules, effectively stacking trades for maximum efficiency.
• Coordinate materials, fixtures, appliances, and deliveries to prevent conflicts and delays.
• Host and document weekly subcontractor meetings to review progress and address issues before escalation.
• Develop and manage site logistics plans including job office setup, staging, dumpsters, portable facilities, fencing, and signage.
• Maintain a full-sized drawing set onsite and redline drawings to produce accurate as-builts.

Quality Control & Installation Standards:

• Review all installation guides and operations manuals to ensure proper installation and warranty protection.
• Hold subcontractors accountable for workmanship and quality.
• Streamline subcontractor operations without sacrificing quality.
• Develop corrective action plans to recover schedule delays.

Safety & Compliance:

• Enforce company safety program and OSHA standards.
• Host mandatory monthly safety meetings.
• Issue PPE to visitors and guests.
• Promptly document and report all on-site incidents and accidents.
• Coordinate with inspectors and manage inspections, permitting, testing, and required observations.

Jobsite Management & Documentation:

• Open jobsite daily on time; manage sign-in procedures; secure and lock site daily.
• Maintain clean, organized, and hazard-free jobsite conditions (including hands-on cleanup when necessary).
• Accept, inspect, and document all deliveries.
• Track and maintain project inventory.
• Utilize Procore for RFIs, daily reports, photos, and schedule updates.
• Maintain accurate daily documentation and reporting.

Budget Awareness:

• Respect project budgets and proactively plan purchases to prevent unnecessary expenses.

Qualifications & Experience:

• Minimum 10 years of retail, restaurant and / or single family construction supervision experience 
• Strong knowledge of construction practices, means, and methods.
• OSHA certification (Plus) If you do not have, we will aid you in getting this.
• Procore experience required (or equivalent project management software).
• Proficient in Microsoft Word and Excel.
• Professional appearance and strong communication skills.
• Fluent in English (Spanish proficiency is a plus).
• Valid driver’s license and reliable vehicle 
• Strong interest in high-end retail, hospitality, or interior construction
• Strong ability to read and interpret construction drawings and specifications
• Highly organized with strong attention to detail
• Must be legally authorized to work in the United States.
• Must own and utilize basic construction tools.

What We Offer:

• Exposure to luxury, design-forward commercial and residential projects
• A collaborative, fast-paced, and professional work environment
• Health, dental, and vision insurance
• Paid time off and holidays

Company Description

Lund-Ross Constructors was founded in Omaha in 1987 by Larry Lundquist. Now in our 40th year in business, we construct projects across the Midwest in the multi-family, educational, religious, non-profit and public sectors.  Best known for the renovation of many of the most iconic buildings in the area, Lund-Ross is also recognized as a construction partner with many non-profit organizations and is a proud supporter of our community.

Currently, we employ a full-time staff of more than 45 people consisting of experienced project managers, superintendents, field engineers, field craftsmen, and administrative professionals, each committed to our clients and the development, construction and long-term success of their facilities.

Our projects have earned more than 30 Excellence in Construction Awards from Associated Builders and Contractors (ABC) including ‘Project of the Year’ four times.

Repeat clients are the basis of our success. Our typical project is a third or fourth effort with a client that trusts Lund-Ross to deliver the same results we have in the past. Contact us about building your next project and a trusted relationship.

Role Description

This is a full-time on-site role located in Omaha, NE for a Pre-construction Manager/Estimator. The role involves managing pre-construction processes, including cost estimation, budgeting, and developing project timelines. Key responsibilities include reviewing project plans, overseeing project scope and specifications, preparing cost estimates, and collaborating with architects, engineers, and subcontractors. The position also requires maintaining strong relationships with clients and ensuring compliance with construction safety standards.

Qualifications

• Experience in Construction, Project Control, and related technical aspects of pre-construction and project management.
• Proficiency in Budgeting and cost estimation to ensure financial and resource planning accuracy.
• Demonstrated Supervisory Skills to manage teams effectively and lead pre-construction processes.
• Knowledge and commitment to Construction Safety practices to ensure workplace safety and compliance with regulations.
• Strong communication, organizational, and problem-solving skills.
• Ability to work collaboratively with cross-functional teams including architects, engineers, and subcontractors.
• Bachelor’s degree in Construction Management, Civil Engineering, or a related field preferred.

Contracts Manager - Construction Focus (Houston, TX)

Location: Houston, Texas

Employment Type: Full-Time

About the Company

Our client is a nationally recognized electrical contractor with a strong presence across the United States, delivering complex electrical construction solutions across commercial, healthcare, mission-critical, industrial, multifamily, infrastructure, and renewable energy projects.

Position Overview

We are seeking an experienced Contracts Manager to join the Houston team. This role will manage contractual processes for major electrical construction projects nationwide, providing strategic oversight, risk mitigation, and contract compliance.

A background as in-house counsel is a plus, particularly for candidates who have supported construction or design-build organizations. This is an exciting opportunity to work with a fast-growing, innovative contractor on high-profile projects that shape industries and communities across the country.

Key Responsibilities

• Draft, review, and negotiate construction contracts, subcontracts, and procurement agreements.
• Provide guidance on contractual obligations, risk management, and compliance with company policies and industry standards.
• Collaborate with project managers, engineers, and leadership to resolve contractual disputes and ensure smooth project execution.
• Advise on legal and business implications of project terms and change orders.
• Maintain contract documentation, track obligations, and ensure timely renewals or amendments.
• (If applicable) Provide in-house counsel support, including risk assessment, contract interpretation, and legal advice for construction projects.

Qualifications

Required:

• Proven experience managing contracts in the construction industry.
• Strong understanding of construction agreements, subcontracts, and change order processes.
• Ability to interpret, negotiate, and enforce complex contractual terms.
• Excellent communication, organization, and problem-solving skills.

Preferred:

• Experience as in-house counsel within construction, engineering, or design-build firms.
• Familiarity with federal, state, and local construction regulations.
• Exposure to risk management, claims resolution, or litigation support related to construction contracts.

Benefits

• Competitive compensation ($110,000-$175,000 DOE + bonus potential)
• 401(k) company match
• Comprehensive medical, dental, and vision coverage
• Generous paid time off plus public holidays
• Professional development and career advancement opportunities
• Collaborative Houston-based team working on high-profile national projects

Project Manager (Mechanical Construction)

Driven by Vision | Powered by Passion

Location: Portland, OR area

Company Overview: Working for global leaders in the aerospace, chemical, steel, pharmaceutical, oil & gas, power generation, and semiconductor industries, BMWC builds facilities that deliver critical products to consumers across the globe. BMWC is a dynamic and forward-thinking construction company. We pride ourselves on being among the most progressive and innovative companies in our field. Our work is fast-paced, diverse and involves projects within rapidly evolving industries. BMWC executes some of the most complex and critical projects in the construction industry. We are passionate about what we do, and we’re looking for a skilled Project Manager to join our team. If you share our passion for executing large, complex, and fast-paced construction projects for customers within rapidly expanding industries, BMWC has an opportunity for you.

Position Summary: As a Project Manager, you’ll play a crucial role in leading and executing construction projects. You will be responsible for managing the development and execution of complex mechanical construction projects ranging from $5M to $30M in direct-hire construction. Leading a team of experienced professionals, you will be responsible for delivering safe projects on time and within budget. If you thrive in a challenging environment and are ready to contribute to our success, we want to hear from you!

Responsibilities:

• Project Planning and Execution:
• Develop and manage project plans, set milestones, and allocate resources effectively.
• BMWC is a self-perform contractor; you will work directly with craft supervision throughout the project lifecycle.
• Monitor project progress, identify risks, and implement corrective actions.
• Execute company safety standards, incentives, and compliance programs.
• Strategic contract management, including commercial terms and craft labor agreements.
• Budget and Cost Management:
• Prepare, manage, and forecast project costs, budget, and overall profitability.
• Monitor and analyze expenses and costs, including labor, material, and equipment.
• Prepare project status reports for BMWC’s leadership team and clients.
• Stakeholder Communication:
• Provide updates for all project phases with necessary stakeholders, including due dates, impacts, and adjustments during the life of the project.
• Liaison and collaborate with clients, subcontractors, and internal teams, proactively following up on requests or issues as needed.
• Client Management:
• Participate in activities/events that promote strong client relationship building.
• Work with the Marketing and Sales Department to pursue new client opportunities, develop proposals, and win new work.
• Team Leadership:
• Lead project teams, motivate team members, and foster a positive work environment.
• Mentor younger employees and prepare them for the next steps in their careers, aligning with BMWC’s core value of “People”.
• Resolve conflicts and facilitate effective communication.

Qualifications and Experience:

• Bachelor’s degree in Construction Management, Engineering, or related field.
• Minimum of 8 years of experience managing industrial construction project teams.
• Proficiency in project management software (e.g., Primavera, Procore, Microsoft Project).
• Strong leadership, communication, and problem-solving skills.
• Demonstrated proficiency in leading and managing cross-functional team members responsible for project controls, estimation, purchasing, safety, quality, and virtual design.

Benefits: We offer one of the best and most comprehensive benefits packages in the industry, as our commitment to employee well-being is critical to our company’s success. Our benefits include day 1 medical coverage and 100% 401K vesting with company match, annual bonuses and profit sharing, and MUCH MORE!

As one of the premier specialty construction companies in the country, our employees enjoy a focus on growth and development, work/life balance, and one of the best safety records in the industry. We are 100% management-owned, making our employees' development and advancement paramount to our success.

Join BMWC Constructors and be part of a team that’s shaping the future of construction!

We are seeking a hands-on, results-driven Director of Construction Operations to lead complex, large-scale developments across high-rise multifamily, commercial, hospitality, and mixed-use projects.

This is a get-it-done construction leadership role requiring deep vertical construction experience, strong field presence, and the ability to drive schedules, control costs, and deliver exceptional quality across multiple projects and regions.

Key Responsibilities

• Lead all phases of construction operations across assigned high-rise and mixed-use projects
• Maintain direct, on-site involvement to ensure schedule adherence, budget control, safety compliance, and quality standards
• Oversee projects exceeding $50M+ in total construction value
• Manage full project lifecycle including pre-construction, budgeting, procurement, execution, and closeout
• Partner closely with architects, engineers, contractors, consultants, and municipal agencies
• Drive cost control, forecasting accuracy, and disciplined change management
• Resolve field challenges quickly to mitigate risk and prevent schedule delays
• Oversee contracts, RFIs, submittals, change orders, schedules, and punch lists
• Collaborate with development and design teams during entitlement and pre-construction phases
• Communicate progress, risks, and milestone updates clearly to executive leadership
• Travel to project sites across multiple states as required

Qualifications

• 7+ years of progressive construction management experience, including luxury high-rise or complex urban developments
• Direct experience in multifamily, hospitality, and/or mixed-use vertical construction
• Proven ability to manage large-scale project budgets ($50M+ minimum)
• Strong knowledge of construction sequencing, high-rise structural systems (concrete, steel, podium), safety standards, and quality control practices
• Bachelor’s degree in Construction Management, Engineering, Architecture, or related field (or equivalent experience)
• Demonstrated ability to manage multiple concurrent projects across different regions
• Highly motivated, decisive, field-oriented leader who thrives in fast-paced environments

Compensation

Compensation commensurate with experience and project scale

Equal Opportunity Employer

We are an Equal Opportunity Employer and value diversity. All employment decisions are made without regard to race, color, religion, sex, sexual orientation, gender identity or expression, national origin, age, disability, veteran status, or any other protected status.

Company Description

Cannon Building, a leading general contractor specializing in life science, healthcare, commercial/institutional, and industrial sectors, is seeking an experienced Superintendent to oversee and drive the successful delivery of healthcare construction projects in the San Diego area.

As a Superintendent at Cannon Building, your primary focus will be the Cannon Building’s Safety Plan at the jobsite. Work with the Project Manager to develop a project schedule. Monitor with and assist the Project Manager in the execution of the project financial goals. Provide quality control by studying drawings, questioning uncertain details, continuously walking the job and inspecting each trades work and compare it to the contract documents. Be a problem solver prior to the work taking place and ensure that the work meets or exceeds the requirements of the contract documents.

Role Description

This is a full-time, on-site role for a Construction Superintendent – Life Science at Cannon Building. Based in Carlsbad, CA, the Construction Superintendent will oversee daily on-site operations of construction projects, ensuring they are executed on time, within budget, and meet quality and safety standards. Responsibilities include managing crews and subcontractors, ensuring compliance with safety protocols, preparing and following project schedules, and coordinating resources and materials to optimize efficiency. The role requires collaboration with project management teams and maintaining clear communication with stakeholders.

Responsibilities:

Project Planning and Coordination:

•  Monitor and document all SWPPP, BMP and storm related paperwork related to the project including job surveys and updating of the SWPPP plans and keeping all files up to date.

Leadership and Communication:

•  Provide leadership by using effective verbal and written communications to manage the subcontractors and field personnel as well as interact with the Owner, Architect and Consultants on behalf of the company.
• Organize and lead project meetings, prepare minutes, and ensure all parties understand and fulfill their obligations.

 Contract and Compliance Management:

• Ensure compliance with general conditions and contract requirements, monitoring contract documents for conformance and execution.
• Negotiate subcontract and purchase order terms, oversee subcontract execution, and manage subcontractor claims.

 Project Documentation and Systems:

• Utilize Procore to manage project documentation and costs, overseeing the preparation and reporting of RFIs, submittals, inspections, safety reports, change orders, and related documents.
• Confirm all contracts are signed and insurance is in place prior to allowing any personnel on the jobsite to perform any work. Reads and has a working knowledge of subcontracts and change orders. Review weekly project logs for insurance, RFIs, Submittals, and Material Delivery Logs to ensure the proper delivery of materials, equipment and labor to the project.
• Review shop drawings along with Project Manager to help ensure compliance with the construction documents.

Quality and Safety Assurance:

• Participate in Operations and Safety meetings, promoting and enforcing jobsite safety.
• Start up the project assessing safety requirements and site logistics. Schedule and document safety start up meetings with the subcontractors reviewing Cannon Building’s safety requirements, OSHA requirements, Site Specific Safety requirements and reporting requirements.
• Monitor work quality and perform regular inspections to ensure construction standards are consistently met.
• Enforce strong safety culture, conducting regular safety meetings, inspections, and ensuring compliance with OSHA and other safety regulations.

Travel Requirements:

•  Travel may be required; the position is based out of the San Diego region, with travel for projects as needed in Orange, Los Angeles, or San Diego counties.

Qualification and Requirements

Experience Requirement: Demonstrates a working knowledge of commercial construction with a minimum of five years of experience in this area with a focus on Life Science and Pharmaceutical

· Education/Training: Bachelor’s degree in construction management, Civil Engineering, or a related field preferred. Additional certifications in OSHPD/HCAI regulations and construction safety are a plus

· Experience as Lead Superintendent for Life Science/Pharmaceutical projects

Project Experience: Project experience valued at $2 Million or greater as a Superintendent.

• Minimum of 5 previous project experience managing Life Science/ Pharmaceutical

Excellent Written and Communication Skills: Candidates must possess excellent written and verbal communication skills, enabling effective interaction with clients, stakeholders, team members, and other project participants. Strong presentation and negotiation skills are essential to manage client expectations and influence project outcomes.

Technical Expertise: In-depth understanding of construction techniques, including reinforced concrete, wood framing methods, and engineering details, as well as electrical, mechanical, and plumbing systems.

Technical Proficiency: Proficient computer skills in Microsoft Office Suite, project management software

(Procore or similar), scheduling software (MS Project or similar), PDF management (Bluebeam), and BIM software (AutoCAD, Revit, Navisworks, or similar).

Strategic and Analytical Thinking: Ability to think strategically and make informed decisions, including analyzing project requirements, assessing risks, and developing effective strategies to meet project goals. Proactive approach to problem-solving.

Financial Management: Advanced skills in budgeting, financial management, and cost control, including developing and monitoring project budgets, tracking expenses, and ensuring financial objectives are met. Experience in managing project contracts and subcontractors.

Risk Management: Deep understanding of risk management principles and techniques, including identifying potential risks, developing risk management strategies, and implementing mitigation plans to minimize project disruptions.

 Quality Assurance: Strong focus on quality control and assurance, ensuring compliance with relevant codes, standards, and specifications. Experience in conducting quality audits and implementing quality control measures.

Client Management: Maintains good working relationships with City Officials and Inspectors. Schedules all City Inspections in advance to ensure schedule commitments are met.

Who We Are:

Cannon Building is a leading Life Science, Commercial/Institutional, Healthcare, and Industrial builder, providing highly efficient, cost-effective construction solutions with a commitment to safety and an uncompromising standard of quality. Cannon Building is proud to be a family-owned business, celebrating its 30th year in operation. We empower our employees to take the lead in achieving their own, unique goals. Our company culture is one of teamwork, inclusiveness, growth, leadership and creativity.

We respect and rely on one another for exceptional results. We promote an environment of collaboration, enjoy working together, and celebrate the success of our clients, knowing that customer success is the basis for our long-term success. To learn more about our work culture, visit our Company Website.

Our Mission: To develop long-term working relationships by providing premier commercial construction services.

Our Vision: To efficiently deliver quality projects with the highest level of customer satisfaction.

Our Values: We are professional, ethical, innovative, and accountable.

Seeking a flexible, detailed oriented team player with the ability to manage multiple tasks, produce quality work, and consistently meet deadlines. Proven expertise in healthcare with a strong network of industry contacts. Experience in Life Sciences, Construction, or similar fields is beneficial.

Compensation:

Salary: $120k to $160k DOE

Offers a competitive compensation package that includes a 401(k) plan with match: employee group dental, vision, life, and disability. Medical insurance, family dental and vision insurance, and supplemental life insurance available with reasonable employee contributions; paid holidays, vacation, and sick time; FSA

• Develop and implement companywide VDC standards and templates.
• Train teams on VDC tools to boost digital proficiency
• Lead BIM/VDC coordination across architectural, civil, structural, and MEP disciplines.
• Develop and maintain discipline specific BIM models.
• Coordinate with project teams, subcontractors, and designers to ensure accurate model-based planning and execution.
• Manage BIM Execution Plans and VDC standards.
• Conduct clash detection and constructability reviews using Navisworks, Revit, Civil 3D, AutoCAD, MicroStation, and Autodesk Construction Cloud.
• Geolocate models for survey alignment, field layout, and spatial coordination.
• Integrate point clouds into Revit, AutoCAD, and Navisworks for design verification.
• Collaborate with Senior Survey Manager to translate models into field layout and verify as-builts.
• Maintain as-built models throughout construction.
• Validate field conditions for QA/QC and coordination.
• Perform and manage 3D laser scanning with Leica, FARO, or Trimble equipment.
• Manage and operate reality capture technologies including drones (FAA Part 107 certification required) and insta 360 cameras for precise geospatial data and visual documentation to support planning, design and construction.
• Ensure organized data management and long-term storage.
• Research and apply emerging construction technologies.
  

• 8–10 years of experience in the construction, engineering, or design industry.
• Minimum 5 years of direct BIM coordination experience.
• Proven expertise in BIM model management and reality capture technologies.
• Proficiency in BIM software: AutoCAD, Civil 3D, Revit, Navisworks, ReCap, and MicroStation.
• Proficiency in scan processing software: Leica Cyclone, FARO Scene, Trimble RealWorks.
• Proficiency with drone operation and data processing tools: DroneDeploy, DJI Terra, Pix4D.
• Solid understanding of survey principles and practices.
• Ability to read and interpret construction documents, including drawings, specifications, schedules, and scopes of work.
• Skilled in interpreting and utilizing scanned point cloud data.
• Highly motivated team player with the ability to work collaboratively across internal and external teams.
• Strong communication skills and a passion for BIM and its impact on construction processes.
• Bachelor’s degree in Architecture, Engineering, or Construction Management
  

• Health insurance
• Dental insurance
• Vision insurance
• Paid time off
• 401K matching
• Flexible spending account
• Life insurance
• Referral program
• Professional development assistance
• Eligibility for Year End Bonus
• LifeLock Subscription
  

Construction Manager Trainee / Assistant Construction Manager

Full-Time | Residential Homebuilding

A nationally recognized, Fortune 500 homebuilder is seeking a Construction Manager Trainee / Assistant Construction Manager to join their team. This is an excellent opportunity for someone looking to build a long-term career in residential construction with a company known for quality, growth, and strong leadership development.

This role is responsible for supporting the construction of homes within an assigned community, ensuring projects are completed on schedule, within budget, and to the highest quality standards.

What You’ll Be Doing

• Partner with experienced Construction Managers on site inspections, project planning, and coordination of trades
• Monitor construction progress to ensure cost, schedule, and quality goals are achieved
• Maintain project documentation including budgets, change orders, and daily reports
• Utilize construction management software (Procore, BuildPro, or similar platforms)
• Conduct and support job-site safety meetings and inspections
• Track daily manpower and document job-site activity with photos
• Record and distribute meeting minutes from on-site meetings
• Coordinate schedules and communicate timelines with trade partners
• Upload and manage RFIs, submittals, and drawing revisions
• Help maintain clean, organized, and safe job sites

What We’re Looking For

• High school diploma required; college degree preferred
• Construction experience is a plus, but not required
• Strong organizational and time-management skills
• Ability to thrive in a fast-paced, team-oriented environment
• Effective written and verbal communication skills
• Proficiency in Microsoft Word and Excel
• Valid driver’s license with good driving record
• Valid auto insurance coverage
• Ability to manage multiple detailed tasks with competing deadlines

Why This Opportunity?

• Clear growth path within a respected national homebuilder
• Exposure to all phases of residential construction
• Hands-on mentorship from senior construction leadership
• Opportunity to build a long-term career in a high-demand industry

We are seeking a qualified Construction Manager that will be able to work in a fast-paced environment managing infrastructure and facility projects for state and municipal clients.  The position involves working with a team of hands-on talented engineers, environmental professionals and construction managers involved in a wide range of projects.

Come join our team! We are looking to build services and capabilities through the growth of our key asset- our staff. Ranked among the nation's top A/E and Construction Management firms by Engineering News-Record, LiRo-Hill  provides construction management, engineering, environmental, architectural, and program management solutions. You can become part of an organization that has a strong track record and is looking to strengthen relationships and capabilities to continue being a trusted resource for our clients in the public and private sector. We are proud to be known as an “Integrated Construction, Design and Technology Solutions” firm and we have delivered on that label time and again.

Recently, Global Infrastructure Solutions Inc. (GISI), the parent company of The LiRo Group and Hill International, Inc. consolidated a portion of the highly experienced staff of both LiRo and Hill in the Northeast to create a larger, more efficient, and cost-effective team to serve clients.  LiRo-Hill is a 1100-person firm with offices in NYC, Long Island, Buffalo, Rochester, Boston, Needham, MA and Edison, NJ.

• Review work to make sure that it is completed in accordance with contract documents.
• Ongoing involvement with the CM team, Client, design consultants and construction contractor teams.
• Participate in on-site reviews, meetings, submittals, and requests for information by contractors.
• Prepare meeting agendas, minutes and documentation as required.

• 1-7 years’ experience
• Associate or bachelor’s degree in Construction Management, Engineering or Architecture.
• Strong communication skills with the ability to work independently and multi-task.

Our Culture:

We believe in the power of collaboration. We work hard to build a corporate culture that empowers all our employees to freely share their ideas, know their presence, and contributions are truly valued, fostering a climate where our employees are enabled to maximize their full potential.

Please visit our website for all of our career opportunities at We offer a competitive salary commensurate with experience, a comprehensive benefits package and a positive work environment. 

- Compensation: Min: $70,000 - Max: $80,000. The range provided is the salary that the Firm in good faith believes at the time of this posting is willing to pay for the advertised position.  Exact compensation will be determined based on the individual candidate's qualifications and location. 

- Visa sponsorship is not available for this role.

LiRo-Hill is an Equal Opportunity Employer. All qualified applicants will receive consideration for employment without regard to age, race, color, creed, religion, national origin, ancestry, marital status, sex, affectional or sexual orientation, gender identity or expression, or protected veteran status; and will not be discriminated against on the basis of disability.

#ID22

#ZR22

#LI22

PI4cad9a71f8ad-3631

The Broward County Board of County Commissioners is seeking qualified candidates for Construction Project Manager-Crane Section at Port Everglades.



The Construction Project Manager in the Operations Division - Crane Section is responsible for performing advanced professional and administrative work in the design and management of crane improvement projects for the Port Everglades Department.

THIS JOB ANNOUNCEMENT WILL REMAIN OPEN UNTIL SUFFICIENT NUMBER OF APPLICATIONS ARE RECEIVED AND MAY CLOSE AT ANYTIME.

General Description

Performs advanced professional and administrative work in the design and management of construction projects for the County.

Works independently, under limited supervision, reporting major activities through periodic meetings.

Requires an associate degree from an accredited college or university with major coursework in architecture, civil engineering, construction management or closely related field.

Requires Eight (8) years of professional engineering and/or construction management experience relevant to the area of assignment or closely related experience.

Possess and maintain a valid Florida Class E Driver's License based on area of assignment.

Ability to secure and maintain a Transportation Worker Identification card (TWIC) within 60 days of employment and for the duration of employment.

• Bachelor's or master's Degree from an accredited college or university with major coursework in Architecture, Civil Engineering, Construction Management, or closely related field
• Project Management Professional (PMP) certification
• LEED certification
• Licensed Engineer in the State of Florida, or Licensed General or Building Contractor in the State of Florida
• 1+ years experience using AutoCAD
• 1+ years experience using Building Information Modeling (BIM)
• 5+ years of experience in governmental accounting and procurement processes
• 3+ years of experience gantry crane maintenance

Duties and Responsibilities

The functions listed below are those that represent the majority of the time spent working in this class. Management may assign additional functions related to the type of work of the job as necessary.

Develop and prepare engineering plans and designs for various crane improvement projects; estimate quantities and costs of such projects.

Assists consultants in the development of construction projects; issues work orders to consultants, surveyors and testing labs; reviews consultant's plans and specifications at various stages of development for conformance to design standards, completeness and accuracy; monitors consultant's cost estimates and verifies consultant's invoices and recommends payment.

Coordinates bid advertisements; schedules and assists in conducting pre-bid conferences; assists in evaluating bids and making recommendations for award of contract.

Schedules and assists in conducting pre-bid construction meetings with consultants, contractors and subcontractors; issues Notice to Proceed to contractors; reviews field inspection reports.

Assists in the preparation of schedules and monitors construction progress; assists in the preparation of change orders; maintains records of consultant's payments.

Assists in the inspection of projects for substantial completion and prepares punch list of any deficiencies; arranges for correction of defects by contractor during warranty period and conducts inspection at end of warranty period to ensure correction of defects.

Prepares required paperwork for capitalizing and closing the project; performs special investigations, sites analyses and feasibility studies as required and submits technical and management reports.

Meets with consultants, contractors, utility organizations, city, state, federal agencies, civic associations, business and community leaders, property owners and attorneys; assists with the preparation of the budget for capital expenditures.

Makes recommendations regarding hiring, discipline and promotions of subordinates; authorizes leave; evaluates employee performance.

Performs related work as assigned.

• Financial Acumen:Interprets and applies key financial indicators to make better business decisions. Determines and estimates the main direct and indirect costs; makes generally appropriate decisions regarding expenditures. Studies financial and quantitative information; uses data to improve performance.
• Manages Complexity:Makes sense of complex, high quantity, and sometimes contradictory information to effectively solve problems. Consistently looks at complex issues from many angles; obtains a rich and deep understanding; swiftly cuts to the core issue; skillfully separates root causes from symptoms.
• Decision Quality:Makes good and timely decisions that keep the organization moving forward. Knows when to act independently and when to escalate issues. Integrates various inputs, decision criteria, and trade-offs to make effective decisions. Typically makes good independent decisions.
• Balances Stakeholders:Anticipates and balances the needs of multiple stakeholders. Ensures that own efforts meet the needs and requirements of internal and external stakeholders. Works to identify all relevant issues and satisfy the interests of multiple stakeholders during the decision-making process.
• Plans and Aligns:Plans and prioritizes work to meet commitments aligned with organizational goals. Stays focused on plans and improvises in response to changes, including risks and contingencies. Aligns own team's work with other workgroups'. Looks ahead to determine and obtain needed resources to complete plans.
• Ensures Accountability:Holds self and others accountable to meet commitments. Accepts responsibility for own work, both successes and failures. Handles fair share and does not make excuses for problems. Usually meets commitments to others.
• Drives Results:Consistently achieves results, even under tough circumstances. Holds self to high standards of performance; sets some challenging goals; wants to achieve meaningful results; pursues initiatives/efforts to successful completion and closure. Focuses on key goals, even during setbacks and obstacles.
• Communicates Effectively:Develops and delivers multi-mode communications that convey a clear understanding of the unique needs of different audiences. Tailors communication content and style to the needs of others. Pays attention to others' input and perspectives, asks questions, and summarizes to confirm understanding.
• Situational Adaptability:Adapts approach and demeanor in real time to match the shifting demands of different situations. Sees even subtle cues to adapt; deploys a wide range of behaviors to stay effective. Exemplifies flexibility and resourcefulness; responds deftly to a variety of challenges and situations.

Physical Demands

Physical demands refer to the requirements for physical exertion and coordination of limb and body movement.

Performs light work that involves walking or standing most of the time and involves exerting up to 20 pounds of force on a regular and recurring basis, or skill, adeptness and speed in the use of fingers, hands or limbs on repetitive operation of electronic office equipment or tools within moderate tolerances or limits of accuracy.

Unavoidable hazards refer to the job conditions that may lead to injury or health hazards even though precautions have been taken.

Involves routine and frequent exposure to traffic; moving machinery.

County Core Values

All Broward County employees strive to demonstrate the County's four core behavioral competencies.

• Collaborates: Building partnerships and working collaboratively with others to meet shared objectives.
• Customer focus: Building strong customer relationships and delivering customer-centric solutions.
• Instills trust: Gaining the confidence and trust of others through honesty, integrity, and authenticity.
• Values differences: Recognizing the value that different perspectives and cultures bring to an organization.

Copyright 2025 Korn Ferry. ALL RIGHTS RESERVED

Broward County is an Equal Opportunity Employer committed to inclusion. Broward County is committed to providing equal opportunity and reasonable accommodations to qualified persons with disabilities. We support the hiring of people with disabilities; therefore, if you require assistance due to a disability, please contact the Professional Standards Section in advance at or email to make an accommodation request.

Note: During emergency conditions, all County employees are automatically considered emergency service workers. County employees are subject to being called to work in the event of a disaster, such as a hurricane, or other emergency situation and are expected to perform emergency service duties, as assigned.

All Broward County employees must serve the public and fellow employees with honesty and integrity in full accord with the letter and spirit of Broward County's Employee Code of Ethics, gift, and conflict of interest policies.

All Broward County employees must establish and maintain effective working relationships with the general public, co-workers, elected and appointed officials and members of diverse cultural and linguistic backgrounds, regardless of race, color, religion, sex, national origin, age, disability, marital status, political affiliation, familial status, sexual orientation, pregnancy, or gender identity and expression.

Overview
Georgia Tech prides itself on its technological resources, collaborations, high-quality student body, and its commitment to building an outstanding and diverse community of learning, discovery, and creation. We strongly encourage applicants whose values align with our institutional values, as outlined in our Strategic Plan. These values include academic excellence, diversity of thought and experience, inquiry and innovation, collaboration and community, and ethical behavior and stewardship. Georgia Tech has policies to promote a healthy work-life balance and is aware that attracting faculty may require meeting the needs of two careers.

About Georgia Tech
Georgia Tech is a top-ranked public research university situated in the heart of Atlanta, a diverse and vibrant city with numerous economic and cultural strengths. The Institute serves more than 45,000 students through top-ranked undergraduate, graduate, and executive programs in engineering, computing, science, business, design, and liberal arts. Georgia Tech's faculty attracted more than $1.4 billion in research awards this past year in fields ranging from biomedical technology to artificial intelligence, energy, sustainability, semiconductors, neuroscience, and national security. Georgia Tech ranks among the nation's top 20 universities for research and development spending and No. 1 among institutions without a medical school.

Georgia Tech's Mission and Values
Georgia Tech's mission is to develop leaders who advance technology and improve the human condition. The Institute has nine key values that are foundational to everything we do:
1. Students are our top priority.
2. We strive for excellence.
3. We thrive on diversity.
4. We celebrate collaboration.
5. We champion innovation.
6. We safeguard freedom of inquiry and expression.
7. We nurture the wellbeing of our community.
8. We act ethically.
9. We are responsible stewards.

Over the next decade, Georgia Tech will become an example of inclusive innovation, a leading technological research university of unmatched scale, relentlessly committed to serving the public good; breaking new ground in addressing the biggest local, national, and global challenges and opportunities of our time; making technology broadly accessible; and developing exceptional, principled leaders from all backgrounds ready to produce novel ideas and create solutions with real human impact.

Department Information
The Campus Services capital projects team enhances the Institute's physical environment by managing design and construction for renovation, infrastructure, access control, and new construction projects that support the department and serve our students.

Direct the contract management and project team activities for one or more large assigned capital building projects from inception to final completion. Responsible for setting employee goals, assessing performance, providing feedback, and making pay recommendations. This position will interact on a consistent basis with: Design & Construction management and staff, Facilities management, contractors, architects. This position typically will advise and counsel: Design & Construction management and staff, Facilities management, contractors, architects. This position may supervise assigned project managers.

Job Duty 1
Oversee the development and negotiations leading to building projects.

Job Duty 2
Prepare RFQ/RFP leading to A& E contracts, construction contracts, design-build contracts and other consulting and construction agreements.

Job Duty 3
Review proposals and recommend contract awards.

Job Duty 4
Manage the design and construction phases of assigned projects.

Job Duty 5
Administer project budgets and schedules.

Job Duty 6
Prepares and presents construction progress reports.

Job Duty 7
Plan, supervise and evaluate performance of assigned staff.

Job Duty 8
Perform other duties as assigned Required Qualifications

Educational Requirements
Bachelor's Degree in Construction Management or related field or equivalent combination of education and experience

Other Required Qualifications
Requires 12 hour work days when involved in supervision of staff working on special projects

Required Experience
Five to six years of job related experience

Additional Preferred Qualifications
Registered Architect, Professional Engineer or Project Management Professional certification , LEED AP certification

SKILLS
This job requires working knowledge the principles and processes associated with construction engineering. Ability in negotiation, contract administration, project management, communications, budgeting, and use of standard and specialized computer applications is required.

The University System of Georgia is comprised of our 25 institutions of higher education and learning as well as the System Office. Our USG Statement of Core Values are Integrity, Excellence, Accountability, and Respect. These values serve as the foundation for all that we do as an organization, and each USG community member is responsible for demonstrating and upholding these standards. More details on the USG Statement of Core Values and Code of Conduct are available in USG Board Policy 8.2.18.1.2 and can be found on-line at policymanual/section8/C224/#p8.2.18_personnel_conduct.

Additionally, USG supports Freedom of Expression as stated in Board Policy 6.5 Freedom of Expression and Academic Freedom found on-line at policymanual/section6/C2653.

The Georgia Institute of Technology (Georgia Tech) is an Equal Employment Opportunity Employer. The Institute is committed to maintaining a fair and respectful environment for all. To that end, and in accordance with federal and state law, Board of Regents policy, and Institute policy, Georgia Tech provides equal opportunity to all faculty, staff, students, and all other members of the Georgia Tech community, including applicants for admission and/or employment, contractors, volunteers, and participants in institutional programs, activities, or services. Georgia Tech complies with all applicable laws and regulations governing equal opportunity in the workplace and in educational activities.

Equal opportunity and decisions based on merit are fundamental values of the University System of Georgia ("USG") and Georgia Tech. Georgia Tech prohibits discrimination, including discriminatory harassment, on the basis of an individual's race, ethnicity, ancestry, color, religion, sex (including pregnancy), national origin, age, disability, genetics, or veteran status in its programs, activities, employment, and admissions. Further, Georgia Tech prohibits citizenship status, immigration status, and national origin discrimination in hiring, firing, and recruitment, except where such restrictions are required in order to comply with law, regulation, executive order, or Attorney General directive, or where they are required by Federal, State, or local government contract.

Salary range: $103,345.00- $117,145.00

Location: Atlanta, GA

Job grade: S8

This is a supervisory position.
This position does not have any financial responsibilities.
This position will be required to drive.
This role is considered a position of trust.
This position does not require a purchasing card (P-Card).
This position will not travel
This position does not require security clearance.

A successful candidate must be able to pass a background check. Please visit employment/pre-employment-screening

Are you an experienced litigation attorney with a background in construction or complex business disputes who is seeking a fully remote role without sacrificing the quality or sophistication of your work? Do you want to collaborate with seasoned litigators on high-exposure matters while enjoying the flexibility of a remote practice? Are you looking for a firm that values excellence, trust, and long-term professional growth?

If so, this opportunity may be an excellent fit.

Scion Legal has been engaged to lead a confidential search on behalf of a respected and well-established multi-office law firm with a strong presence across the Southwest and Western United States. The firm is seeking a Construction and Business Litigation Attorney to support its Irvine, California office, with the role structured as fully remote.

LEGAL OPPORTUNITY OVERVIEW

This is a compelling opportunity for a motivated and detail-oriented attorney with 2 to 7 years of experience to join a sophisticated construction and business litigation practice in a fully remote capacity. Attorneys in this group handle complex, high-value matters and work closely with experienced partners, clients, and insurance carriers across a wide range of industries and jurisdictions.

Despite the remote structure, attorneys are fully integrated into case teams and entrusted with meaningful responsibility across all phases of litigation.

WHAT YOU WILL DO

• Represent clients in complex construction and business litigation matters
• Handle disputes involving design professionals, contractors, manufacturers, developers, and property owners
• Draft and argue motions, pleadings, and discovery responses
• Participate in depositions, mediations, arbitrations, trials, and appellate matters
• Provide strategic counsel to clients and insurers throughout the lifecycle of construction projects, including claims guidance during active design and construction
• Work on matters involving large-scale infrastructure, public works, and commercial developments such as transportation projects, healthcare facilities, hospitality properties, utilities, and residential developments
• Collaborate remotely with partners and litigation teams while maintaining a high level of responsiveness and professionalism

WHAT YOU BRING

• J.D. from an ABA-accredited law school
• Active bar membership in good standing in at least one U.S. jurisdiction
• 2 to 7 years of experience in construction law, complex litigation, or business litigation
• Strong legal writing, analytical, and advocacy skills
• Prior experience working with insurance carriers or insured clients is strongly preferred
• Ability to manage matters independently in a remote environment while contributing effectively to a team-based practice

COMPENSATION AND REMOTE STRUCTURE

• Base Salary Range: $130,000 to $190,000, depending on experience and overall fit
• Fully remote role aligned with the Irvine, California office
• Exposure to sophisticated, high-value litigation and nationally significant construction projects
• Collaborative culture with experienced trial attorneys and meaningful mentorship
• Clear long-term growth and advancement potential

This is a rare opportunity to join a well-regarded construction and business litigation practice while enjoying the flexibility of a fully remote role tied to a premier Southern California office.

ABOUT OUR SEARCH FIRM:

Scion Staffing is a national, award-winning staffing firm! Since 2006, we have had the pleasure of successfully placing thousands of talented professionals with amazing career opportunities. Through our innovative team building and recruiting solutions, we bridge the gap in executive leadership searches, direct hire recruiting, interim leadership placement, and temporary professional staffing.

We are proud to be part of the Forbes lists of the Best Recruitment Firms and the Best Executive Search Firms in America. Additionally, Scion has been recognized as a ClearlyRated Best of Staffing firm as well as a top recruitment firm by The Business Times. Additional information about our firm can also be found online.

Scion Staffing, Inc. is an equal opportunity employer and service provider and does not discriminate based on race, religion, gender, gender identity, national origin, citizenship status, sexual orientation, disability, political affiliation or belief, or any other protected class. We are committed to the principles of Equal Opportunity Employment and are dedicated to making employment decisions based on merit and value, for ourselves, our client companies, and the candidates we represent.

For opportunities located in a region that have enacted fair chance, arrest or conviction-based employment ordinances, Scion Staffing proactively follows the enacted guidance and considers for employment all qualified applications with arrest and conviction records. We engage in socially conscious business practices and believe that diverse, inclusive, and non-biased talent and recruitment processes are foundational to the success of Scion as well as every client organization with whom we partner.